Full Text
CONSTRUCTION CONTRACT STREET PATCH AND OVERLAY - 2003 THIS CONTRACT, dated this 8th day of July, 2003 by and between the City of Moscow, Idaho, a municipal corporation of the State of Idaho (hereinafter 'City') and Poe Asphalt Paving, Inc., (hereinafter 'Contractor'): W ITNESSETH: WHEREAS, pursuant to the invitation of the City, extended through an officially published "Advertisement for Bids", the Contractor did, in accordance therewith file with the City a proposal containing an offer which was invited by said notice; and WHEREAS, the City has determined that said offer was the lowest and best submitted: NOW THEREFORE, the parties to this Contract, in consideration of the mutual covenants and stipulations set out, agree as follows: ARTICLE 1. CONTRACT DOCUMENTS The Contract Documents which comprise the entire agreement between the City and the Contractor concerning the wort< to be performed are this Contract, pages one through four and the following: 1. Advertisement for Bids; 2. Project SpeCifications titled: STREET PATCH AND OVERLAY· 2003; 3. Bid/Proposal of the Contractor, dated June 25, 2003, physically attached to this Contract; 4. The Engineering Plans; 5. Performance and Payment Bonds and Insurance Certificates, physically attached to this contract; 6. Addenda issued prior to opening of bids (n/a this contract); 7. Change Orders which may be delivered or issued after the effective date of this Contract. There are no Contract Documents other than those listed in Article 1. This Contract may only be amended by change order as provided in the General Conditions. ARTICLE 2. WORK The Contractor shall complete the entire work as specified, indicated and required for Division I I only under the Contract Documents for City of Moscow project titled: STREET PATCH AND OVERLAY- 2003 ARTICLE 3. CONTRACT TIME I SUBSTANTIAL COMPLETION The work to be performed pursuant to this Contract shall be substantially complete on or before August 22, 2003, unless adjustment of the contract time is made in accordance with the provisions of the Contract Documents. The Contractor shall begin work in conformance with the Contract Documents and shall complete the wort< prior to the date of completion. PAGE 1 • CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE 4. CONTRACT SUM The City shall pay the Contractor for completion of the work in accordance with the Contract Documents in current funds the amount of forty-six thousand three hundred five dollars ($46,305.00). Said Contract Sum shall be paid in accordance with the Contract Documents. ARTICLES. INDEPENDENT CONTRACTOR The parties warrant by their signature that no employer-employee relationship is established between the Contractor and the City by the terms of this contract. It is understood by the parties hereto that the Contractor is an independent contractor and as such neither it nor its employees, agents, representatives or subcontractors, if any, are employees of the City for purposes of tax, retirement system, or social security {FICA) withholding. ARTICLES. SCOPE OF SERVICES The Contractor shall perform all services required by the Contract Documents. All work shall be completed in accordance with the plans and specifications established for this project. ARTICLE 7. HOLD HARMLESS f INDEMNIFICATON In addition to other lights granted the City by the Contract Documents, the Contractor shall indemnify and save harmless the Engineer and the City, its officers and employees, from all suits, actions, or claims of any character brought because of any injuries or damages received or sustained by any person, persons, or property on account of the operations of the Contractor or his subcontractors; or on account of or in consequence of any neglect in safeguarding the work; or because of any act or omission, neglect, or misconduct of the Contractor or his subcontractors; or because of any claims or amounts recovered from any infringements of patent, trademark or copyright; or from any claims or amounts arising or recovered under the Workmen's Compensation Act or any other law, ordinance, order or decree. ARTICLES. CONFLICT OF INTEREST The Contractor covenants that it presently has no interest and will not acquire any interest, direct, or indirect, in the project which would conflict in any manner or degree with the performance of its services hereunder. The Contractor further covenants that, in performing this Contract, it will employ no person who has any such interest Should any conflict of interest arise during the performance of this Contract, Contractor shall immediately disclose such conflict to the Project Engineer I Engineer and the City. ARTICLE 9. ENTIRE AGREEMENT, MODIFICATION AND ASSIGNABILITY This Contract and the exhibits hereto contain the entire agreement between the parties, and no statements, promises, or inducements made by either party, or agents of either party are valid or binding unless contained herein. This Contract may not be enlarged, modified or altered except upon written agreement signed by the parties hereto. The Contractor may not subcontract or assign its rights (including the right to compensation) or duties arising hereunder other than as contemplated by the Contract Documents, without the prior written consent and express authorization of the City. PAGE 2- CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE 10. ADHERENCE TO LAW REQUIRED All applicable local, state and federal statutes and regulations are hereby made a part of this Contract and shall be adhered to at all times. Violation of any of these statutes or regulations by the Contractor shall be deemed material and shall subject the Contractor to termination of this Contract for cause. No pleas of misunderstanding or ignorance on the part of Contractor will in any way serve to modify the provisions of this requirement The Contractor and his surety shall indemnify and save harmless the City and its employees, agents and representatives against any claim or liability arising from or based on the violation of any such laws, codes, ordinances, or regulations, whether by himself, his employees, or his subcontractors. ARTICLE 11. LEGAL FEES In the event either party incurs legal expenses to enforce the tenms and conditions or this Contract, the prevailing party is entitled to recover reasonable attorney's fees and other costs and expenses, whether the same are incurred with or without suit ARTICLE 12. SPECIAL WARRANTY The Contractor warrants that nothing of monetary value has been given, promised or implied as remuneration or inducement to enter into this Contract The Contractor further declares that no improper personal, political or social activities have been used or attempted in an effort to influence the outcome of the competition, discussion, or negotiation leading to the award of this Contract. Any such activity by the Contractor shall make this Contract null and void. ARTICLE 13. COMMUNICATIONS Such communications as are required by this Contract shall be satisfied by mailing or by personal delivery to the parties at the following address: Contractor: Poe Asphalt Paving, Inc. P.O. Box784 Pullman, WA 99163 City: City of Moscow P.O. Box 9203 Moscow, ID 83843 PAGE 3 • CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE 14. EXECUTION IN WITNESS WHEREOF, said Contractor and the City have caused this Contract to be executed on the day and year first above written. /X Contractor: Poe Asphalt Paving, Inc. City: . /1 ' / ; ; ACKNOWLEDGMENT State of 7 cl ) ss N'c ۲ County of ) I ( On this day of vc۳ LA , 2003, before me, a Notary Public of the State of personally appeared /?he rk /b.e_ (President), iJ i { and ( A. (Secretary) in their official capacity as president and secretary of Poe Asphalt Paving, Inc. known to me to be the persons described in the above document and acknowledged to me they executed the same. If I lJ Notary :îlie . resi a W ashiogtoo dee:<. e:;:ocn heeby ڱ S.1"0:-J£BRAr:::ER.: J۱ BE.v.ilTT: DO:S: McQCARY:fl-!ERYL A ASHBY: DELtA J_ Alllۯ: {,_'b,t۶CU:Xt.. W its txue and: tawftA .3rtomey(:s۰t.JC!.. '••tlh ftdl a.Ahcrity 10 exe<,-u!e on it:> 1idcliry JC'd surety t:.ona:; ot undert;)i- and oltoef dot::vm.-ۃ of a 91nil¥ Cs:sued in tho-: cou:r"'£ ol its OO:sڼ . .3nd to tind the ͩJi\re Company mer-etry 1N Wlfl'..tESS WHEREOF'. SAFECO !NSURAN"CE CONIP.AN'f OF AMERICA .dl'ld GrnERAL INSURANCE COMPANY OF AMERJCA h..JVe exec:u:ed arte>-te.1 ͨ this l.Jd>. . R.A P'IERSON_ S£CRETARY CSHlACATE &fJJy bond 0( undert:ing of !heۘ- theۅ Of" aۄ ltld'-eo( -rruy beۗM al'bͫ oo: Jn a11y ڏ H ہ: ۂ- L. "lh.""lt !he sealÏ۔ n« be ھto lhe=ol ÖOif×ۭ- Extract &"om a Res:oiu!X:n of 1hr Boa.d ot OWےۓ d. SAFECO INSt.JRANCE COUP AN'f OF .AMERJCA .and d GEMERAL COUP ANY OF AUERJCAÎ Jdy 2R. tg out. The of Af1ide v. À 13 of tbr ڽ .and. (iii) Au::.pyot کڪ-d-:a.norn.eyÁ ګڬt ڭ- ;ao1 {ii} ڷ that:s:aid ۦۧÕi'i intua beeۖ dfea:. the s:ignatae or lhe-ۙotik::er' .may be byN- and the ڸofڹÆ"?¥ be a bc.;in* l!leteof.- t. RA _ Seo-e:Ury of SAFE CO INSی COMP' ...llt.t« OF AMERICA and d G.£NElV.L Ct».tP ANY OF /I..M£RJCA. 00 hefd:y c;;-ed;fy ttwt " fur"e<:_ptng ۉ-<1 Ct)of;rect_ .and th4f txll:n the the Rڲ .ornd the Ëof Ntocney ڶ :slil in f>A forte :and etkct.. IH WITNESS W1i£RE()IF, I tQve be!euoto sod my h;.x1 Ä atfixe.d theÅ _Sf."--dl of ͥlion- S---097-USAEF 7.ʹ͵ R.A P'tERSOU, Sf::CR£TARY tR) HͲlun"J tfͷ\.of$J>,;£C0C<OJbC" >113t::l'J rof ---PAGE BREAK--- SAFE C 0' BID BOND SAFECO INSURANCE COMPANY OF AMERICA GENERAL INSURANCE COMPANY OF AMERICA FIRST NATIONAL INSURANCE COMPANY OF AMERICA HOME OFFICE: SAFECO PLAZA SEATTLE, WASHINGTON 98185 KNOW ALL B y TllESE PRESENTS, That we, Poe Asphalt Paving, Inc. W A (hereinafter called the Principal), as Principal, and SAFECO !NSCRANCE COMPAl\t' OF AMERICA (hereinafter called the Surety), as Surety, are held and finnly bound unto Ci¥y (hereinafter called the Obligee) in the penal sum of 5% of Bid Amount Dollars($ 5% of Bid Amount for the payment of which the Principal and the Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, finnly by these presents. THE CONDITION OF THIS OBLlGATIOA' IS SUC11, That IHIEREAS, the Principal has submitted or is about to submit a proposal to the Obligee on a contract for Patch & '2003 NOW, THEREFORE, If the said Contract be timely awarded to the Principal and the Principal shall, within such time as may be specific¨ enter into the Contract in writing._ and give bond, if bond is required, with surety acceptable to the Obligee for the faithful performance of the said Contract, then this obligation shall be void-, to remain in full force and effect, Signed and scaled this _.:1.::6ccth::_ _ _ _ day S-53 R811t75 J©uªn«e ,20p I (Seal) Principal , I ECO Il\St:RAI\CE COMPAI\Y OF AMERICA Della J. Allen Attom1;y-in-fact PRINTED IN U.S.A_ ---PAGE BREAK--- SAFE C O PERFORMA\ICE BO'\D Bond No. 6179139 K'\OW ALL BY THESE PRESE\TS, That we, Poe Asphalt Paving, Inc. (hereinafter called the Principal), as Principal, Safeco Insurance Company of America , a corporation duly organized under the laws of the State of Washington (heremafter called the Surety), as Surety, arc held and firmly bound unto jn the sum the City of Moscos forty six thousand, three hundred five dollars ta.£J2ͤo Principal WJ"-' Della J. Allen Attorney-in-Fact 5·0757 GEEF 7196 I I I I I ---PAGE BREAK--- V SAFECC J'OC.A .;:N:ERN.- ڢ LUMf?.I'NY Of' AJ.tf.RJCA ttC»..€ Of'HCE SAS'ECO 9\..AZA $£ATH.L WASHINGTON 96185 Tm1t SAFE CO INSURANcE COM? At« OF A.lo&ERlCA .Jnd GE..NERAL INSURANCE COMP ldiY OF AMERICA. e;:,ch a W a· <:ocpoGltion. dces eۋ h͞y - · f'H!l ST():-;EBRAITR_JAMFS 1'-t. HEWITT: McQCARY. CH(RYL .-\_ASHBY: DELL"\ 1_ ALLfڣڤ Cl.ut">-l=ctet ion the ͛ of itsڥ"'»- 30(.1' to bind ltte re;pec.tive company ttlereby WfTNE$.._'S" WHERE-C'F". SAFECO I:NSURANCE COMPANY OF AMERICA and GE'NERAt. INSURANCE COMP' ANY OF .AMERICA. h:.Nͳ eR'O.t:txl arx! :artesfed l:he--;e present. dayol RA Pt£:n$0N. SCCR.ETAA.Y W. RANOA1_L STOOOARO. PR£Sl0Eta Extr.x:t from lhe By t..aws ot SA.f£CO INSURANCE COMPANY OF .A.UERfCA and o!GE:NER.Al.. WSUR.A:H<::t: COMPANY OF ANE:NJCA.: . -ڇ V. Sect.ioo 13.- FIOEl.JTY AND SÍETY BONOS !he PresiOeot.. :.wry V.ce PJ-ړ1ent., !he Seaet:J(y. 3nd ͗ N;;si:s.bot V>ee Prڻ Ôted fo..-ttl.at ͖ by the officer io ڴ of sڙ º shatl each»¼ toÒ iodividuals as ¶--i.n-bct or uu()e,f ol:t>d .3J:p'qwialoe: titles wil:h authority to e:JCeCUI:e on beh.-llf of tile cornpany tKietay and sa..-ety bonds olhd" ڒts ol µ ڂ by lhe ڃ in !he È at it; bus;oes..--..-ͣ Oo 3tlY څ m.ڑ K such ڮtrnent. the Ies may be atfuo:ed by G- Oo any J confenlog ڵ à ot" on any bood 0( ځ of the COlږ. 1he seal.. ۚaN lbereo( may be imp'M or at!Ued oc in any olhe1 H ڿ ۀ-L-that the .se;Ji Ïە na beđtothe=ofany s;uctlۮot×-- Extod '&-om a Resolution ol r2'loe ao..d ot Oif"ڊ ol SAfE CO INSt.TRAHCE COMPANY e ¾ aod of ͕ ol A'ilotney Cued theceto. ae nue ;anc:_l CDcC\ tbe By-Laws. theۆ ¥1d theË ol A1.1omey xe slil inڈ b-ee and پ rN WTThiESS wtfEREOF". 1 have ١ s-et rrry b..:Jfld Ä JJfuted OleÅ :s:.ea1 of s."»d ٽ RA PIERSON, SECR....CT.A.RY RfK_;r;.tan;O" 5113/'.YJPOf' ---PAGE BREAK--- SAFECO PAYMENT BOND BOND NO. KNOW ALL BY THESE PRESENTS, That we. Poe Asphalt Paving, Inc. {Here insert the name and address or legal title of Contractor) as Principal, hereinafter called Principal, and SAFE CO INSUR.ANCE COMPANY OF AMERICA, a Washington Corporation, as Surety, hereinafter called Surety, are held and finnly bound unto the City of Moscow (Here insert the name and address or legal title of Owner) as Obligee, hereinafter called Owner. for the use and benefit of Claimants as herein ddincd, in the amount of forty six thousand, three hundred five dollars and 00/lOO Dollars($ 46,305.00 (Here insert a sum equal to at least one-half ofthc contract price) for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators. successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has by \\Tirtcn agreement dated _ 2003 entered into a contract with Owner fOr Street Patch and Overlay³ 2003 in accordance with the terms and conditions of said contract. \:vhich is hereby reterrcd to and made a part hereof NOW, THEREFORE. THE CONDITION OF THIS OBLIGATION IS SUCII That if the Principal shall make payment to all Claimants as hereinafter defined. for all labor and material used or reasonably required f()r usc in the performance of the Contact, then this obligation shall be void; otherwise shalt remain in fulJ f(Jrcc and effect. subject, however. to the following conditions: L A Claimant is defined as one having a direct Contract with the Principal or with a Subcontractor of the Principal tOr labor. material, or both, used or reasonably required for use in the performance of the Contact, 2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every Claimant as herein dcfmed, who has not been paid in full befOre tht: t:Xpiration of a period of ninety (90) days after the date on which the last of such Claimants work or labor was done or peformed. or materials were fumished hy such Claimant may sue on this bond for the use of such Claimant, prosecute the suit to final judgment fOr such sum or sums as may be justly due Claim:mt, and have execution thereon. 3. No suit or action shall be commenced hereunder by any Claimant a) Claimant. other than one having a direct Contract with the principaL shall have given notice to any two of the fOllowing: The Princpal, the Owner, or the Surety above named, within ninety {90) days after such Claimant did or performed the last of the work or labor, or furnished the Last of the materials for which said claim is made, b) After the expiration of one ( 1) Year tOllowing the date on which Principal ceased work on said Contract. lf the provisions of this paragraph are void or pmhibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. c) Other than in a state court of competent jurisdiction in and tlx the connty or other political subdivision of the state in \Vhich the Project or any part thereofĐ is situated. or in the United States CGurt for the district in whieh the Project or ::my part thereof is situated. and not elsewhere. 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good t3ith hereunder. Signed and sealed this 22nd S-4174/SAEF 2!97 day of July 2003 Poe Asphalt Paving, Inc . Principal TU &tLS.t:mill.aj- SAFECO INSURANCE COMPANY OF AMERJCA Attorney-in-Fact ---PAGE BREAK--- S SAFECC ;r tOlOW ALl BY nn;,:.sC PRESENTS: POWER OF ATTORNEY \J"ECO!CQA;IPANYOf ͘Rle:.A. ͙£RN_ ͚ C011.6"HfY Of PJ•££)lCA ̈́ SAf'€CO Pl..AZA Sf.AHl_£ WA?UN(;TON 96U\5 Trot SAFE CO 1NSURANLt COMP )l..}Ct A.U.EFJCA :J:tx1 GENERAL INSURA.NCE COMPANY OF AMERlCA. ext> :a W J· ډtioo. <:k.es exn he:n>:t>y 3-pCX- - - - S"'f0:-.l'£BRARfiC J.AM.fٴS M. HEWll fٵ DO'.: McQt:A.'tY: CHERYL A A-SHB-Y_ l CI..uX:s.tcn. its true ar-:1 t.7wfuJ .JIT01ney(:::}C:ٹ-t:ٺ. wiltt fuU 4'.ahonty to exe<;:ute on it:; be-hatf f.dehty :;wd ->=ety t>oot1:'> or' tlt>t.k"''t."Vq:;: ;Jnd ott'lef of d s.Ornil.;-. Ch..lGU<'͔l >o me ol>ts and ro tinct tt>c rڞ comp:;ڟy ڠcl:Jy »4 wn͋,; WHEREOF·. $.A.ITCO ¥N.SURANCE COMPANY OF .AMERlCA .J.nd GtH D\ol$UR.ANCE CC.>MPANY OF ,Al.KE:RlCA tۍ :artes1•,.J !l'M͑ pce-.;.ent &tJoe $.eo-ebry. andٸ A'i.--ci;-;.twlt V>Ct Pr٨٩ ٣ted to..- th:.:.olt pt..>qx',c by 1he officer- in t.:hao͇ ̾ :<>ur-ety º:shalt t""٢ »¼to.ښڛ; dS ¶چor utl()or ͊ 1:itfes. w-ith ٳl"l..*y to 0('1 t.>dl<1lt Qf ͆ ژy bdd.ty and ٤d:Y l;:or)ds- .:lWld o.lheT do<:::omet>ts ol µ dtctef i::;.sued by ̽ ̓v-ent  or K -such ٔ!:ment. the Iڐ m:J'f be- atti.:xed by On any J eod oc ot ltJ.e uxq:>arny. llw: 'b=irnik- lhd"e-;>( JR,;1:'f be « a1b.ed oc in -any oltW':1' Hڎ)ICed; poov1&:<::iAed by the $.ecxrl:aory Ol" :.on ٕbot Ñ ot 1he Compaoy ¹ out. The ot JllrOde v- SeaX.-13 of !hoe By٪٫- ACOfJ"'dtlle&4-:.l.).dtre•t.'(t'lt'oel'"eto.* A +that saOd -is In tun foc-L""e eiJcd,. ̼ ٓe of ۸toec_.ertl)Ong oCSce,- m.J'f be byG- and ۹te-:s.e3&" ofٖ Cٗ may ̻eoC I. H . ٰٱof SAFE CO COM:P .ANY OF JU,II£FaCA. .and d G.E1IlERAL JNSI.»'tANCE COUP ANY OF A..W.ERlCA,. d:h tile By٭. 1t>e .-.nd the ۇ ol ̿ .sbl in f>A ̺ and enect. l'H WfiNESS W'1-fERE()Fٲ l have٠ s.cl my h.Jw":d ¸ :atfixed 1t>e G se-.zt ot s:lid o:•p:x:ti:>o RA Plf:RS-ON, SECRETARY ́ RO<_;n:lu<.,.;J $AELCOC½"1""'" :;rt fDF ---PAGE BREAK--- ACORQM CERTIFICA OF LIABILITY INSURJ .CE I DATE (MM/DDIYYYY} 07/22/2003 PRODUCER (509)758-5529 FAX (509)758-5311 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION Stonebraker McQuary Agency ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR 616 5th St. ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. PO Box 9 Clarkston, WA 99403 INSURERS AFFORDING COVERAGE NAIC# INSURED Poe As ph a 1 t Paving, Inc. INSURER A CNA/Transcontinental Insurance < o. PO Box 449 INSURER 8 Gulf Insurance Group Lewiston, ID 83501 INSURER C State Insurance Fund INSURER D CNA/Continental Casualty INSURER E COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. !NSR A D B c A so· TYPE OF INSURANCE GENERAL UAB!UTY x COMMERC!Al GENERAL LiABILITY I CLAIMS MADE 0 OCCUR j Stop Gap Liability GEN'l AGGREGATE LIMIT APPLIES PER Xl POLICY n jl8-f n LOC AUTOMOBILE LIABILITY X ANYAUTO - ALL OWNED AUTOS - SCHEDULED AUTOS x HIRED AUTOS x NON"OWNED AUTOS - - ANY AUTO =lAGE LIABILITY j]ESS/UMBRELLA LIABILITY OCCUR D CLAIMS MADE DEDUCTIBLE RET;;:;NTION $ 10,00( WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETORIPARTNERIEXECIJT!VE OFFlCERfMEMBER EXCLUDED? If yes, descnbe under SPECIAL PROV:S:ONS below ifril' ER d • an Mar1ne POLICY NUMBER TCP1078605171 BUA2025665448 CU2823950 578551 10 DAY NOTICE OF CANCELLATION ONLY TCP1078605171 POLICY EFFECTIVE POLICY EXPIRATION LIMITS 11/01/2002 11/01/2003 EACH OCCURRENCE ' 1,000,005 DAMAGE 10 RENTED ' 100,000 MED EXP (Any one person} $ 5,000 PERSONAL & ADV iNJURY ' 1,000,000 GENERAL AGGREGATE $ 2,000,005 PRODUCTS - COMPIOP AGG s 2,000,000 11/01/2002 11/01/2003 COMBINED SINGLE LIMIT (Ea accrdent) s 1,000,000 BODILY INJURY s (Per person) BOOIL Y INJURY s (Per accident} PROPERTY DAMAGE s (Per acc1dent) AUTO ONLY • EA ACCIDENT ' OTHER THAN EA ACC s AUTO ONLY AGG ' 11/01/2002 11/01/2003 Ei>,CH OCCURRENCE ' 4,000,005 AGGREGATE $ 4,000,000 ' s $ 10/01/2002 10/0l/2003 I .fc\miTiiJH;; I x I 0Jk E L EACH ACCIDENT s 500,005 E L. DISEASE EA EMPLOYE s 500,000 EL. DISEASE· POLICY liMIT $ 500,005 11/01/2002 11/01/2003 $200,000 Installation Floater $500 Deductible ff.ESCRIPT!ON OF OPERATIONS I LOCA T!ONS I VfiH!CLES 1 E)tCt_USIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS he City of Moscow, Idaho 1s add1t1onal insured (except on work comp) as respects work performed pn their behalf on the Street Patch and Overlay 2003 project. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL (){MAIL _1Q_ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, City of Moscow IOO!OO®tkll