Full Text
CONSTRUCTION CONTRACT THIS AGREEMENT, dated this 7th day of February, 1995, by and between the City of Moscow, Idaho, a municipal corporation of the State of Idaho (hereinafter, "City") and Dickerson Pump & Irrigation Co., Inc. , (hereinafter, "Contractor") : WITNESSETH: WHEREAS, pursuant to the invitation of the City, extended through an officially published "Advertisement for Bids", the Contractor did, in accordance therewith file with the City a proposal containin;7 an offer which was invited by said notice; and I ( \ WHEREAS, the City has determined that said offer was the lowest\ and best submitted: NOW THEREFORE, the parties to this Contract, in consideration of the mutual covenants and stipulations set out, agree as follows: ARTICLE 1. CONTRACT DOCUMENTS The Contract Documents which comprise the entire agreement between the City and the Contractor concerning the work to be performed are this Contract, pages one through and the following: 1. Advertisement for Bids; 2. Project Specifications titled : WELL 9 PUMP RENOVATION - 1995; 3. Bid/Proposal of the Contractor, dated January 31, 1995, to be physically attached to this Contract; 4. The Engineering Plans; 5. Performance and Payment Bonds and Insurance Certificates, to be physically attached to this Contract; 6. Change Orders which may be delivered or issued after the effective date of this Agreement; 7. Addenda issued prior to opening of bids, to be physically attached to this contract. There are no Contract Documents other than those listed in Article 1. This Contract may only be amended by change order as provided in the General Specifications. CONSTRUCTION CONTRACT PAGEl 95-08 ---PAGE BREAK--- ARTICLE 2. WORK The Contractor shall complete the entire work as specified, indicated and required under the Contract Documents. ARTICLE 3 . CONTRACT TIME/SUBSTANTIAL COMPLETION The work to be performed pursuant to this Contract shall be substantially complete on or before May 15, 1995, unless adjustment of the contract time is made in accordance with the provisions of the Contract Documents. The Contractor shall begin work in conformance with the Contract Documents and shall complete the work prior to the date of completion. ARTICLE 4. CONTRACT SUM The City shall pay the Contractor for completion of the work in accordance with the Contract Documents in current funds the amount of Twenty-eight Thousand Five Hundred Twenty-three DOLLARS ($28,523. 00). Said Contract Sum shall be paid in accordance with the Contract Documents. This amount is subject to modification per INSTRUCTION TO BIDDER: IB-16 BID ITEM SELECTION. ARTICLE 5. INDEPENDENT CONTRACTOR The parties warrant by their signature that no employer-employee relationship is established between the Contractor and the City by the terms of this contract. It is understood by the parties hereto that the Contractor is an independent contractor and as such neither it nor its employees, agents, representatives or subcontractors, if any, are employees of the City for purposes of tax, retirement system, or social security (FICA) withholding. CONSTRUCTION CONTRACT PAGE2 ---PAGE BREAK--- ARTICLE 6 . SCOPE OF SERVICES The Contractor shall perform all services required by the Contract Documents. All work shall be completed in accordance with the specifications and plans established for this project. ARTICLE 7. HOLD HARMLESS/INDEMNIFICATION In addition to other rights granted the City by the Contract Documents, the Contractor shall indemnify and save harmless the Engineer and the City, its officers and employees, from all suits, actions, or claims of any character brought because of any injuries or damages received or sustained by any person, persons, or property on account of the operations of the Contractor or his subcontractors; or on account of or in consequence of any neglect in safeguarding the work; or through use of unacceptable materials in constructing the work; or because of any act or omission, neglect, or misconduct of the Contractor or his subcontractors; or because of any claims or amounts recovered from any infringements of patent, trademark or copyright; or from any claims or amounts arising or recovered under the Workmen' s Compensation Act or any other law, ordinance, order or decree. ARTICLE 8. CONFLICT OF INTEREST The Contractor covenants that it presently has no interest and will not acquire any interest, direct or indirect, in the project which would conflict in any manner or degree with the performance of its services hereunder. The Contractor further covenants that, in performing this Contract, it will employ no person who has any such interest. Should any conflict of interest arise during the performance of this Contract, Contractor shall immediately disclose such conflict to the Project Engineer/Engineer and the City. ARTICLE 9 . ENTIRE AGREEMENT, MODIFICATION AND ASSIGNABILITY This Contract and the exhibits hereto contain the entire agreement between the parties, and no statements, promises, or inducements made by either party, or agents of either party are valid or binding unless contained herein. This contract may not be enlarged, modified CONSTRUCTION CONTRACT PAGE 3 ---PAGE BREAK--- or altered except upon written agreement signed by the parties hereto. The Contractor may not subcontract or assign its rights (including the right to compensation) or duties arising hereunder other than as contemplated by the Contract Documents, without the prior written consent and express authorization of the City of Moscow. ARTICLE 10. ADHERENCE TO LAW REQUIRED All applicable local, state and federal statutes and regulations are hereby made a part of this contract and shall be adhered to at all times. Violation of any of these statutes or regulations by the Contractor shall be deemed material and shall subject the Contractor to termination of this contract for cause. No pleas of misunderstanding or ignorance on the part of the Contractor will in any way serve to modify the provisions of this requirement. The Contractor and his surety shall indemnify and save harmless the City and its employees, agents and representatives against any claim or liability arising from or based on the violation of any such laws, codes, ordinances, or regulations, whether by himself, his employees, or his subcontractors. ARTICLE 11. LEGAL FEES In the event either party incurs legal expenses to enforce the terms and conditions of this contract, the prevailing party is entitled to recover reasonable attorney' s fees and other costs and expenses, whether the same are incurred with or without suit. ARTICLE 12. SPECIAL WARRANTY The Contractor warrants that nothing of monetary value has been given, promised or implied as remuneration or inducement to enter into this Contract. The Contractor further declares that no improper personal, political or social activities have been used or attempted in an effort to influence the outcome of the competition, discussion, or negotiation leading to the award of this Contract. Any such activity by the Contractor shall make this Contract null and void. CONSTRUCTION CONTRACT PAGE4 ---PAGE BREAK--- ARTICLE 13. COMMUNICATIONS Such communications as are required by this contract shall be satisfied by mailing or by personal delivery to the parties at the following address: Contractor: City: Dickerson Pump & Irrigation Co., Inc. P. O. Box 2823 Spokane, WA 99220 City of Moscow 122 E. 4th Street P. O. Box 9203 Moscow, Idaho 83843 IN WITNESS WHEREOF, said Contractor and the City have caused this Contract to be executed on the day and year first above written. Contractor: / Presideil CONSTRUCTION CONTRACT PAGE 5 ---PAGE BREAK--- ACKNOWLEDGMENT day of r:vwbvut:&v\J, , 1995, before me, a the State \of\ re!(lf'P'ersonally appeared in the officiit::t, capacity as President , and • in the officialĸĹ capacity as Secretary, known to me to be acknowledged to the person described in the above document and me he executed the same./'\, ' ,l !Ji ··-ɄɅ-Ɇ I. I I I /lj z:l \ )mn1 i":fr/o T; Ɩvi, ) 1-!Cltar¥ Ppjil;;i!c re'siding at -)wfuiiE:::f ACKNOWLEDGMENT On this day of 1995, before me, a Notary Public of the State of Idaho, personally appeared Paul c. Agidius in his official capacity as Mayor of the City of Moscow, known to me to be the person described in the above document and acknowledged to me he executed the same. On this day Notary Public of the Russell in her official be the person described she executed the same. CONSTRUCTION CONTRACT PAGE6 Notary Public residing at My Commission expires ACKNOWLEDGMENT of 1995, before me, a State of Idaho, personally appeared Elaine capacity as Moscow City Clerk, known to me to in the above document and acknowledged to me Notary Public residing at My Commission expires ---PAGE BREAK--- II • • • • • • • • • 11 • I • • • I • I BID PROPOSAL TO: Mayor and City Council City of Moscow, Idaho Date: 1/31/95 This proposal is submitted as an offer by the undersigned to enter into contract with the City of Moscow, Idaho as represented by the City Council, hereinafter referred to as the 'CITY' for WELL 9 PUMP RENOVATION - 1995, specified herein and which construction documents are on file with the City Engineer, City Hall Annex, Moscow, Idaho, and which are a condition hereof with the same force and effect as though they were attached hereto. The offer is conditioned on the following declarations as to the facts, intention and understanding of the undersigned and the agreement of the CITY to the terms and prices herein submitted . 1. 2 . 3 . 4 . 5. ?age 2 All project specifications and drawings examined by the undersigned and their terms and conditions are hereby agreed to . The undersigned certifies that he has received or made himself aware of any and all existing site conditions that may affect the proposed work. It is understood that the contract drawings may be supplemented by additional drawings and specifications in explanation and elaboration of the contract drawings and it is agreed that such supplemental drawings, when not in conflict with those referred to in paragraph 1 aboĺ.re, Ķ,;ill have the same force and effect as if attached hereto and that when received they will be considered a part of the contract . The undersigned will furnish separate performance and payment bonds in the full amount of the contract price . The cash, certified check, bid bond, or cashier1S check. accompanying this proposal shall be forfeited to the of Moscow, Idaho to the extent of 5% of the amount bid if the undersigned shal: fail or refuse to execute the contract, furnish performance and payment bonds, ---PAGE BREAK--- II II • • • • • • I I I I I I 0 I I I 6. 7 . 8. and insurance certificate as required by the specifications within the tķme limit therein after notification that the said proposal is accepted, all in accordance with the provisions of this proposal and the specifications . The undersigned further agrees that the CITY shall have the right to accept or reject any bid item deemed to be in the best interest of the City. The undersigned agrees to order all necessary equipment and materials within a period of three days after Notice to Proceed has been issued by the City Engineer . The undersigned, as a bidder, Number through to him and have been examined documents. acknowledges that Addenda have been delivered as part of the contract 9. The undersigned agrees to complete all work embraced in the contract by the date set forth in paragraph IB-13 of the Instruction to Bidders. 10. The undersigned holds Idaho State Contractor's License Number 12522AA-1 1 1 . The undersigned certifies that the information contained in the STATEMENT OF BIDDER'S QUALIFICATIONS is true and correct. It is understood that the CITY shall reject any proposal from a bidder whose experience is less than that which is specified in INSTRUCTION TO BIDDERS IB-17 . 12. The undersigned proposes to use the following sub contractors in the performance of meeting the contract requirements: Subcontractors Trade Specialitv Amount a. c. ?age 3 ---PAGE BREAK--- I I I I I I I I I I I I I I I I I 13. The undersigned proposes to furnish labor, materials, equipment and services of all kinds required for WELL 9 PU}lP RENOVATION - 1995, as described in the specifications, including all appurtenant work, all as required by the specifications and this proposal for the prices in accordance with the completed schedule contract prices as follows: Page 4 ---PAGE BREAK--- I I BASE BID SCHEDULE I ITEM DESCRIPTION LUMP SUM NO. PRICE I 1. Building removal and replacement $ 980.00 I 2. Pull and re- install pump/motor and pump column $ 7280.00 I 3. Pump inspection $ 950.00 I 4. Motor inspection $ 1950.00 5 . Power cable inspection $ 400 00 I 6. Motor storage $ 600.00 I 7. Factory motor rebuild - Actual cost plus (this price includes shipping and handling)DOES NOT include factory rebuild $ 2950.00 I cost or freight.' 8. Pump renovation ll a. Replace series case bearings $ 1610.00 b. Replace pump shaft $ 2980 00 c. Add bowl case wear rings $ 1750.00 I d. Machine trim impeller hubs/ verify impeller balance $ 560.00 e. Furnish and install new I ss fasteners $ 360.00 f. Furnish and install new gaskets and seals $ 350.00 I g. Replace greases $ h. Replace strainer screeJJ. (stainless steel) $ 1095.00 I i. Sandblast and coat bowl assembly exterior $ 300.00 fl j . Replace cable guard $ 580.00 9. Replace flat cable assembly $ 2640.00 I 10. Replace air line $ 500.00 I I Page 5 ---PAGE BREAK--- II II I I • • • • • • • • • • • • • Well disinfecthon s 200.00 12. Replace Ca::hodic protection assembly 488.00 TOTAL BASE BID $ 28.523.00 ALTERNATE BID SCHEDULE A-1 Complete bowl assembly replacement 17,873 00 No. Incorporated) :Jated at Spokane, wa Dickerson Pump & Irrigation Co., Inc • Firm Name of Bidder Bert H. Kolbeck President Official Title PO Box 2823 Spokane. Wa 99220 Mai:ing A-ddress 12522AA-1 Public Works iicense Washington Sta:.e of Inc::rporated This _31_ day of _ 1995; ?age 6 ---PAGE BREAK--- ' II l(i >Z,c I I • • I I I I I I I I STATEMENT OF BIDDER'S QUALIFICATIONS (MUST BE INCLUDED WITH THE BID) Each bidder submitting a proposal on work included in these specifications shall prepare and submit as part of his bid, the data requested in the following schedule: 1. Name of Bidder: Dickerson Pump & Irrigation Co., Inc. 2. 3. 4. 5. 6. 7. 8. 9. Date: Page 7 Business Address: E. 3627 Broadway, Spokane, Wa 99202 How many years has said bidder been engaged in the contracting business under the present firm name: Contracts now in hand (gross amount) $ 100,000.00 General character of work performed by said company: Pump & Irrigation systems Sales & Service List irrigation or municipal wells (5 minimum) where the bidder has pulled and repaired 250 horsepower submersible, deep- well pump/mo tor assemblies. City of Moscow Moscow, Id Trentwood Irrigation District Spokane, Wa City of Kettle Falls Kettle Falls, Wa City of SpokIP -k--IRl_I_G_AT_I()N C:()·_iSi!jf1· Principal FIDELITY AND DEkSJ.,T COMPANY OF MARYLAND ---PAGE BREAK--- Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFICE, BAL TIMOAE, MD KSOW ALL MEC BY THESE PRESENTS: That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. a corporation of the State of Maryland. by C. M. PECOT, JR., Vice-President, and C. W. ROBBINS, Assistant Secretary, in pursuance of authority granted by Article VL Section 2. of the By-Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full force and effect on the date hereof, does hereby nominate, constitute and appoint P • P . , J r . , Robert J . Jones , Dwight B. Aden, James A. Brown, Janice I. Shuey and Richard A. Merritt, all of Spokane Wash in ton . . . . . . ' 1 s rue an aw u agent an orney-m- act, o m e. execute. sea an r. or, an a as surety. an as Jts act and deed: any and all bonds and undertakings STATE OF MARYLA:"'D COt:i" to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 12.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract. 12.4 Owner Default: Failure of the Owner. which bas neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other tenns thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL Company: (Corporate Seal) Signature: Name and Title: Address: SURETY: Company: (Corporate Seal) Signature: Name and Title: Address: CONFORMS TO AMERICAN INSTITUTE OF ARCHITECT DOCUMENT A-312, DECEMBER 1984 EDITION. 3 C3!0 ---PAGE BREAK--- Fie lity and Deposit Col/ any HOME OFFICE OF MARYLAND BALTIMORE, MD. 21203 Bond No. 30587494 Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall he considered plural where applicable. CONTRACTOR (Name and Address): DICKERSON PUMP & IRRIGATION CO. , INC. P 0 BOX 2823 SPOKANE WA 99220 OWNER (Name and Address): City of Moscow 122 E 4th St. PO Box 9203 Moscow ID 83843 CONSTRUCTION CONTRACT Date: February 7, 1995 SURETY Fidelity and Deposit Company of Maryland P.O. Box 1227 Baltimore, Maryland 21203 Amount:Twenty-eight Thousand Five Hundred Twenty-three Dollars ($28,523. 00) Description (Name and Location): Well 9 Pump Renovation - 1995 BOND Date (Not earlier than Construction Contract Date): February 21, 1995 Amount:Twenty-eight Thousand Five Hundred Twenty-three Dollars ($28,523. 00) Modifications to this Bond: llQ None 0 See Page 3 CONTRACTOR AS PRINCIPAL Company: Dickerson Pump & Irrigation Co., Inc. , fi / 1 9!rpo'* Seal SignaturekM/tf· A.-o Name afid Title: (Any additional signatures appear on page 3) SURETY Company: F and Deposit of Maryland / 1 l/ ( . 1/ f z· Corporate Seal Signature: p/Lfi'r:·.q i F t Name and / : an lee uey , A wrney- n- ac v (FOR INFORMATION ONLY-Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or Jones & Mitchell other party): PO Box 2786 Spokane WA 99220-2786 (509) 838-3501 CONFORMS TO AMERICAN INSTITUTE OF ARCHITECT DOCUMENT A-312, DECEMBER 1984 EDITION. C3l0--l ---PAGE BREAK--- 1 The Contractor and the Surety,_-§ 'tly and severally, bind themselves, their heirs, executors, at.. .Ustrators, successor and assigns to the Owner to pay for labor, materials and equipment fur nished for use in the performance of the Construction Contract, which is incorporated herein by reference. 2 With respect to the Owner, this obligation shall be null and void if the Contractor: 2.1 makes payment, directly or indirectly, for all sums due Claimants, and 2.2 Defends, indemnifies and holds hannless the Owner from claims. demands, Hens or suits by any person or entity whose claim, demand, lien or suit is for payment for labor, materials or equipment furnished for in the performance of the Construc tion Contract, provided the Owner has notified the Contractor and the Surety (at the address described in Paragraph 12) of any claims, demands, liens or suits and tendered defense of such claims, demands, Hens or suits to the Contractor and the Surety. provided there is no Owner Default. 3 With respect to Claimants, this obligation shall be null and void if the Contractor makes payment, directly or indirectly, for all sums due. 4 The Surety shall have no obligation to Claimants under this Bond until: 4.1 Claimants who arc employed by or have a direct contract with the Contractor have given notice to the Surety (at the ad dress described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy. the amount of the claim. 4.2 Claimants who do not have a direct contract with the Contractor: .1 Have furnished written notice to the Contractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were fur nished or supplied or for whom the labor was done or performed; and . 2 Have either received a rejection in whole or in part from the Contractor. or not received within 30 days of fur nishing the above notice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and . 3 Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address describ ed in Paragraph 12) and sent a copy, or notice thereof, to the Owner. stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 5 If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety, that is sufficient compliance. 6 When the Claim7 _,-as satisfied the conditions of Paragraph 4, the Snrety sball prort., .J and at the Snrety's expense take the follow ing actions: 6.1 Send an answer to the Claimant. with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that arc undisputed and the basis for challenging any amounts that arc disputed. 6.2 Pay or arrange for payment of any undisputed amounts. 7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shaH be credited for any payments made in good faith by the Surety. 8 Amounts owed by the Owner to the Contractor under the Con struction Contract shall be used for the performance of the Con struction Contract and to satisfy claims, if any. under any Con struction Performance Bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract arc dedicated to satisfy obligations of the Contractor and the Sure ty under this Bond, subject to the Owner's priority to usc the funds for the completion of the work. 9 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that arc unrelated to the Construc tion Contract. The Owner shall not be liable for payment of any costs or expenses of any Claimant Wider this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of. or otherwise have obligations to Claimants under this Bond. 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related sub contracts, purchase orders and other obligations. 11 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the work or part of the work is located or after the expira tion of one year from the date ( 1) on which the Claimant gave the notice required by Subparagraph 4.1 or Clause 4.2.3, or on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of or first occurs. If the provisions of this Paragraph are void or prohibited by law. the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shalJ be applicable . 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date receiv ed at the address shown on the signature page . 13 Wben this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted and provisions conforming to such statutory or other legal require ment shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. CONFORMS TO AMERICAN INSTITUTE OF ARCHITECr DOCUMENT A-312, DECEMBER 1984 EDITION. 2 C3JQ-.! ---PAGE BREAK--- 14 Upon request by any person or er appearing to be a poten tial beneficiary of this Bond. the Cont -d>r shall furnish a copy of this Bond or shall pennit a copy to be made. IS DEFINITIONS 15.1 Claimant: An individual or entity having a direct con tract with the Contractor or with a subcontractor of the Con tractor to furnish labor, materials or equipment for usc in the performance of the Contract. The intent of thls Bond shall be to include without limitation in the tenns labor. materials or equipment that part of water. gas, power. light, heat, oil, gasoline, telephone service or rental equipment used in the Con struction Contract. architectural and engineering services MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: required for p( '"1113.ncc of the work of the Contractor and the Contractor\_ 11bcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor. materials or equipment were furnished. 15.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 15.3 Owner Default: Failure of the Owner. which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perfonn and complete or comply with the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS Company: (Corporate Seal) Signature: Name and Title: Address: SURETY: Company: (Corporate Seal) Signature: Name and Title: Address: CONFORMS TO AMERICAN INSTITUTE OF ARCHITECT DOCUMENT A-312, DECEMBER 1984 EDITION. 3 C31{}-! ---PAGE BREAK--- Power of Attorney FIDELITY AND DEPOSIT COMPANY OF MARYLAND HOME OFFlCE. BAl..TlMORE, MD K:--;OW ALL !v1EN BY THESE PRESENTS: That the FIDEUTY AND DEPOSlT COMPANY OF MARYLAND, a corporation of the State oi Maryland . by C. M. PECOT, JR. Vice-President. and C. W. ROBBINS. Assistant Secretary, in pursuance of authority granted by Art ide VL Section 2. of the By-Laws of said Company, which are set forth on the reverse side hereof and are hereby certified to be in full for-ce and effect on the date hereof. does hereby nominate, constitute and appoint P. P . Jr., Robert J. Jones, Dwight B. Aden, James A. Brown, Janice I. Shuey and Richard A. Merritt, all of Spokane, Washin§ ton, EACH , . . . . . . . Hs true :1n !awful agent an wrnev-m- ac , o m e. execute, sea an er, or, an as suretv, an 1ts act and deed: any and all bonds and ndertakings s : . e execution of such bonds or undertakings in pursuance o e as binding upon said Company, as fully and amply. to all intents and purposes. as if they had been duly exe d ackno by the regularly elected officers of the Company 'lln - O> ""'eJ j hi:__ .J:.;,~AI-sisumtS.c V.ce-, Sr.t_IT OF MARYLASI) I ® CotƊTI oF BAI nwuu: \ ss v On thiS day oL <'\jlJ:.i.L m D 19 . before the subscriber, a Notary Public of the State o f Maryland, duly commissioned and qualified. carne C. M. PECOT, JR., ViceƋPresident and C. W. ROBBINS, Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, to me personally known to be the individuals and officers described in and who executed the preceding instrument, and they each acknowledged the execution of the same, and being by me duly sworn, severally and each for himself deposeth and saith. that they are the said officers of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seal of said Company, and that the said Corporate SeaJ and thejr signatures as such officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation. IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed my Official Seal the day and year first above written. r· I - CAROL J. FADER Notary Public My Commission ExpJresƌƍ- - -8-J!lUtLL.Ƒlm _ CERTIF1CATE I, the undersigned. Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. do hereby certify that the original Power of Attorney of which the foregoing is a full. true and corrƒt copy, is in full force and effect on the date of this certificate; and l do further certify that the ViceƓ President who executed the said Power of Attorney was one of the additional Vice-Presidents specially authorized by the Board of Directors to appoint any Attorney-in-Fact as provided in Article VI, SectJon 2. of the By-Laws of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND. This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the !6th day of July, !969, RESoLVED: ''That the facsimile or mechlmical!y reproduced signature of any Assistant Secretary of the Company, whether made heretofore or hereafter, wherever appearing upon a ce.rtified copy of any power of attorney issued by the Company, shaH be valid and binding upon the Company with the same force and effect as though manually affixed.'' IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this c.cc day oL , I 9 U42& -180-4119 ---PAGE BREAK--- Jones & Mitchell P . o . Box 2 7 86 Spokane , WA 9 9 2 2 0 ( 50 9 ) 8 3 8 - 3 5 0 1 Fax ( 5 0 9 ) 8 3 8- 3 5 1 1 INSUllED DICKERSON PUMP AND IRRIGATION CO. , INC . P 0 BOX 2 8 2 3 SPOKANE , WASHINGTON 9 9 2 2 0 COMPANY A FEDERATED INS CO LETTER COMPANY B LETIER COMPANY c l.El1ER COMPANY D LETlER COMPANY E l.El1ER THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POUCY PERIOD INDICATED, NOlWITHSTANDING ANY REQUIREMENT, TEAM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POUCIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TEAMS, EXCLUSIONS AND CONDITIONS OF POUCIES. UMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. Ɂ CUIMS MADE OWtafS & CONTRACTOfS PROT. : AUTOMOBLE UASIUTY A X ANY NJTO AlL 0\\'NED AUTOS SCHEDULED AUTOS HIRED AUTOS NQN..OVy'NEO AUTOS GARAGE LWIIJIY A X UMBREllA FOAM O'I'H8Z! THAN UMBRELLA FORM WORKER'S COMPENSAllON AHD EMPLOYERS' UABUJTY POLICY NUMBER 609417 609417 609417 DESCRIPTION OF OPERA.TlOHSILOCATIONSIVEHICLESISPEClAL rtEMS i POUCY EFFECTtVE POUCY EXPIRATION i DATE (MMIOOf(Y) DATE {MMit>DJYY) 05/0 1 /9 4 05/0 1 /9 4 : F!RE DAMAGE (My one fire) $ : MEO. EXPENSE {Arry one person). $ : COMBINED SINGLE ) LIMIT 0 5 / 0 1 / 9 5 BOOU IDJRY ƍ (Per pafS:)I'l} : BODILY !N.AJRY ɂ {Per accident} • • • : PROPERTY DAMAGE $ 0 5 / 0 1 / 9 5 EACH ACCIDENT ' DISEASE - POLICY LIMIT DISEASE - EACH EMPLOYEE $ CITY OF MOSCOW NAMED AS ADDITIONAL INSURED AS RESPECTS WELL #9 , PUMP RENOVATION - 1 9 9 5 . MOSCOW 9 20 3 IMCISCOW, IDAHO 8 3 8 4 3 SHOULD ANY OF lliE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILLIL MAIL DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, ƎllllEXlJI)J!Mll!.XK!!!:!Cll!liJ!'li!X'l!J!IKIX111'RƏƐJEttl!l):: ---PAGE BREAK--- Jones & Mitche l l P . o . Box 2 786 Spokane , WA 9 9 2 2 0 ( 50 9 ) 8 3 8 - 3 5 0 1 Fax ( 50 9 ) 8 3 8 -3 5 1 1 INSURED DICKERSON PUMP AND IRRIGATION CO. , INC . P 0 BOX 2 8 2 3 SPOKANE , WASHINGTON 9 9 2 2 0 1 9 9 5 AS A MAlTER OF INFORMATION ONLY AND CONFERS NO RIGHTS THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POUCIES BELOW. COMPANIES AFFORDING COVERAGE COMPANY A FEDERATED INS co LETTER COMPANY B LETTER COMPANY c LETTER COMPANY D LETTER COMPANY E LEITER THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD !NDiCATED, N01W!THSTANDING ANY REQUIREMENT, TERM 011 CONDITION OF ANY CONTRACT OR OTHER DOCUMENT W!TH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, lliE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, E?R:@CJ: MAIL _.JQ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, osti1KIWL191!l1'1'0'M.'il::SPI,O,!.I!;JI0'!lllN2011 ---PAGE BREAK--- THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED • OWNERS, LESSEES OR CONTRACTORS (FORM B) This endorsement mod»ies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name of Person or Organization: CITY OF MOSCOW PO BOX 9203 MOSCOW ID 83843-1703 (If no entry appears above, information required to complete this endorsement will be shown in the Declarations as applicable to this endorsement.) WHO IS AN INSURED (Section II) is amended to include as an insured the person or organization shown in the Schedule, but only with respect to liability arising out of your ongoing operations performed for that insured. Job or Project: CONTRACTORS LICENSES ORDINANCE #94 02 WELL PUMP RENOVATION - 1995 Insured: DICKERSON PUMP & IRRIGATION CO INC PO BOX 2823 SPOKANE WA 99220 CG 20 10 (10-93) Copyright, Insurance Services Office, Inc., 1992 Policy Number: 609417 Effective: 02/28/95