Full Text
CONSTRUCTION CONTRACT THIS CONTRACT, dated this 21st day of March, 2000 by and between the City of Moscow, Idaho, a municipal corporation of the State of Idaho (hereinafter 'City') and Seal Tech, Inc., (hereinafter 'Contractor'): WITNESSETH: WHEREAS, pursuant to the invitation of the City, extended through an officially published "Advertisement for Bids", the Contractor did, in accordance therewith file with the City a proposal containing an offer which was invited by said notice; and WHEREAS, the City has determined that said offer was the lowest and best submitted: NOW THEREFORE, the parties to this Contract, in consideration of the mutual covenants and stipulations set out, agree as follows: ARTICLE 1. CONTRACT DOCUMENTS The Contract Documents which comprise the entire agreement between the City and the Contractor concerning the work to be performed are this Contract, pages one through four and the following: 1. Advertisement for Bids; 2. Project Specifications titled: MANHOLE SEALING • 2000 3. Bid/Proposal of the Contractor, dated March 11, 2000, to be physically attached to this Contract; 4. The Engineering Plans; 5. Performance and Payment Bonds and Insurance Certificates, to be physically attached to this contract; 6. Change Orders which may be delivered or issued after the effective date of this Contract; 7. Addenda issued prior to opening of bids. There are no Contract Documents other than those listed in Article 1. This Contract may only be amended by change order as provided in the General Conditions. ARTICLE2. WORK The Contractor shall complete the entire work as specified, indicated and required under the Contract Documents. ARTICLE 3. CONTRACT TIME I SUBSTANTIAL COMPLETION The work to be performed pursuant to this Contract shall be substantially complete by September 15, 2000, unless adjustment of the contract time is made in accordance with the provisions of the Contract Documents. The Contractor shall not begin work prior to July 1, 2000. PAGE 1 - CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE4. CONTRACT SUM The City shall pay the Contractor for completion of the Work in accordance with the Contract Documents in current funds the amount of thirty-four thousand five hundred eighty dollars ($34,580.00). Said Contract Sum shall be paid in accordance with the Contract Documents. ARTICLE 6. INDEPENDENT CONTRACTOR The parties warrant by their signature that no employer-employee relationship is established between the Contractor and the City by the terms of this contract. It is understood by the parties hereto that the Contractor is an independent contractor and as such neither it nor its employees, agents, representatives or subcontractors, if any, are employees of the City for purposes of tax, retirement system, or social security (FICA) withholding. ARTICLES. SCOPE OF SERVICES The Contractor shall perform all services required by the Contract Documents. All work shall be completed in accordance with the plans and specifications established for this project. ARTICLE7. HOLD HARMLESS /INDEMNIFICATON In addition to other rights granted the City by the Contract Documents, the Contractor shall indemnify and save harmless the Engineer and the City, its officers and employees, from all suits, actions, or claims of any character brought because of any injuries or damages received or sustained by any person, persons, or property on account of the operations of the Contractor or his subcontractors; or on account of or in consequence of any neglect in safeguarding the work; or because of any act or omission, neglect, or misconduct of the Contractor or his subcontractors; or because of any claims or amounts recovered from any infringements of patent, trademark or copyright; or from any claims or amounts arising or recovered under the Workmen's Compensation Act or any other law, ordinance, order or decree. ARTICLES. CONFLICT OF INTEREST The Contractor covenants that it presently has no interest and will not acquire any interest, direct, or indirect, in the project which would conflict in any manner or degree with the performance of its services hereunder. The Contractor further covenants that, in performing this Contract, it will employ no person who has any such interest. Should any conflict of interest arise during the performance of this Contract, Contractor shall immediately disclose such conflict to the Project Engineer I Engineer and the City. ARTICLE 9. ENTIRE AG REEMENT, MODIFICATION AND ASSIG NABILITY This Contract and the exhibits hereto contain the entire agreement between the parties, and no statements, promises, or inducements made by either party, or agents of either party are valid or binding unless contained herein. This Contract may not be enlarged, modified or altered except upon written agreement signed by the parties hereto. The Contractor may not subcontract or assign its rights (including the right to compensation) or duties arising hereunder other than as contemplated by the Contract Documents, without the prior written consent and express authorization of the City. PAGE 2 - CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE 10. ADHERENCE TO LAW REQUIRED All applicable local, state and federal statutes and regulations are hereby made a part of this Contract and shall be adhered to at all times. Violation of any of these statutes or regulations by the Contractor shall be deemed material and shall subject the Contractor to termination of this Contract for cause. No pleas of misunderstanding or ignorance on the part of Contractor will in any way serve to modify the provisions of this requirement The Contractor and his surety shall indemnify and save harmless the City and its employees, agents and representatives against any claim or liability arising from or based on the violation of any such laws, codes, ordinances, or regulations, whether by himself, his employees, or his subcontractors. ARTICLE 11. LEG AL FEES In the event either party incurs legal expenses to enforce the terms and conditions or this Contract, the prevailing party is entitled to recover reasonable attorney's fees and other costs and expenses, whether the same are incurred with or without suit ARTICLE 12. SPECIAL WARRANTY The Contractor warrants that nothing of monetary value has been given, promised or implied as remuneration or inducement to enter into this Contract. The Contractor further declares that no improper personal, political or social activities have been used or attempted in an effort to influence the outcome of the competition, discussion, or negotiation leading to the award of this Contract. Any such activity by the Contractor shall make this Contract null and void. ARTICLE 13. COMMUNICATIONS Such communications as are required by this Contract shall be satisfied by mailing or by personal delivery to the parties at the following address: Contractor: Seal Tech, Inc. · 325 Road Independence, OR 97351 City: ARTICLE 14. EXECUTION City of Moscow 122 E. 4th Street P.O. Box 9203 Moscow, ID 83843 IN WITNESS WHEREOF, said Contractor and the City have caused this Contract to be executed on the day and year first above written. Contractor: × ·Ja i'!reiideni'Y Secretary PAGE 3- CONSTRUCTION CONTRACT ---PAGE BREAK--- ACK NOWLEDG MENT On this day of 2000, before me, a Notary Public of the State of personally appeared ';7115 1 ( Jif:;/ zb f r( · . in their official capacity as i'FeSiee.li;rlt!l President and . :ory>of Seal Tech, Inc., known to me to be the persons described in the above document and acknowledged to me they executed the OFFICIAL SEAL RUTH TRINE NOTARY PUBLIC-OREGON COMMISSION NO. 310213 I EXPIRES MARCH 5, 2002 (seal) PAGE 4- CONSTRUCTION CONTRACT ---PAGE BREAK--- 'ID: M3yor and City Council City of Moscow, Idaho BID PROFOSAL cate: 0 This proJ;X)S8.l is subn:itted as an offer b.i t...'1e undersigned to enter :into contract with the City of Moscow, Idaho as represented cy t.'oe City Council, hereinafter referred to as the 'CITY' for MANHOLE SEI\Ll1iG - 2000, specified here:in and 1/tri.ch construction docurrents are on file with the City Ebg:i:neer, City Hall Annex:, M::>scw, Idaho, and are a condition hereof with the sarre force and effect as though they W')re attached hereto. The offer is conditioned on the following declarations as to the facts, :intention and understs:ndir>g of the undersigned and the agree:rent of the CITY to the terms and prices here:in subn:itted. 1. All project specifications and drawings examined cy the undersigned and their terms and conditions are herel:>y agreed to. 2. '.!he undersigned certifies that be bes receive:i or xrede himself aware of any an:l. all existing site conditions that rray affect the proposed w:>rk. 3. It is understoo<:l. that the contract drawings rray ba supplerrented cy additior.al drawings and specifications :in explanation and elal:oration of the contract drawings and it is agreed that such supplerrental drawings, when not :in conflict with those referred to :in paragraph 1 above, will have the sarre force and effect as if attached hereto and that when receive:i they will ba considered a part of the contract. 4. '!be undersigned will furnish seprrate perfonrer.ce and p:>.yrrent l:onds in the full arrount of the contract price. 5. '.!he cash, certified check, bid bond, or cashier's check accarpanying this proJ;X)S8.l shall ba forfeited to tha City of Moscow, Idaho to the extent of 5% of tha arrount bid if the undersigned shall fail or refuse to execute the contract, furnish perfomance and payrrent l:onds, and insurance certificate as r€q1.lired cy the specifications within the t:ine limit therein after tlOtification that the said prcposal is accepted, all :in accordance with the provisions of this prop::>sal and the specifications . 6. '.!he undersigned further agrees that the CITY shall have the right to accept or reject any bid itan deare:l. to ba in the best interest of the City. 7. '.!he undersigned agrees to order all necessary equiprent and rraterials within a p:>.riod of days after Nbtice to Proceed bes been issued cy the City Ebg:i:neer. 8. '.!he Rigned, as a bidder, that l\&Jenda Number Lft through 9 have been delivere:l. to him and have been examined as part of the contract docurrents. Page 2 ---PAGE BREAK--- 9. 'l'he l.ll"ldersigned agrees to all work El."!tlraced in the contract within the tine limi.tations set forth in paragraph IB-13 of the L.'1Struction to Bid:lers. 10. 'l'he l.ll"ldersigned holds Idaho State Contractor's License Nurrber 14258-D-4(44) 11. 'l'he l.ll"ldersigned p:n;rposes to use the following sub-contractors in the pecto:rn:ance of rreeting the contract requirenents: Sul:x:ontractors Trade Specialty Idaho Public lf..brks License No. $ Arrount b. 12 . 'l'he l.ll"ldersigned prcposes to furnish labor, materials, e:;tlliprent and services of all kinds required for MI\NOOLE SEAtJN::l - 2000 as described in the specifications, including all aa;mtenant work, all as required by the specifications and this proposal for the prices in acco:n'lance with the schedule contract ces as follows : Ita:n Ita:n N:l. Description l. M:lbilization 2. Grout leaks in nenholes 3. 1\j;ply SP-15 coating- Vertical walls 4. 1\j;ply RsnOeroc SP-15 coating- Manhole benches Quantity & Unit 1 Sum 15 nenholes 397 Vertical feet 53 Manholes '1'ol:al Bid • " Unit Price $210 QQ perM.H. $65 00 Pet:" V.F. $85 Oil Pet:" M.H. $ Ú.sÖO,OQ Total Price $1.120.00 $3,l5Q,QO $25,8Q5.QO $4.5Q5.00 Page 3 ---PAGE BREAK--- Seal Tee h, Inc. Finn Natre of Bid'ler fB Sf!AL (if incol:]:Xlrat:e::l.) Date::l. at 'Ibis day of 2000. President Official Title 325 Road Indepeneence, Or. 97351 Mriling Address 14258+4(44) Public Works License NO. Page 4 ---PAGE BREAK--- ·.STERliNG SAVINGS BANK 111 NORTH WALL STREET IE, WASHINGTON 99201 [PHONE REDACTED] SEAL TECH INC. CASHIERS CHECK Ɯ1a1·ch 13, ?000 DATE REMITTER · '**One Thousand Seven Hundred Twenty·nine Dollars and No $*****1,729.00 PAY -nÑooWME•ÒwÓiÕiÔÛBv8cCNiMuw]^oc"FEATi"®¯----··---·- TO THE ORDER OF u• **CITY OF Ɲ10SC01'1** VOID AFTER 180 DAYS STERLING SAVINGS BANK Onwu· I. t.O 500008 '1811' ---PAGE BREAK--- /!bit: INSURANCE Bond Number: PB9259 Performance Bond Premium: $865.00 For the CBIC branch nearest you, call toll free: (888) 283-2242 (888) 293-2242 FAX KNOW ALL BY THESE PRESENTS, That we, called the Principal, and CONTRACTORS BONDING AND INSURANCE COMPANY, a Washington corporation, called the Surety, are held and firmly bound unto _ called the Obligee, in the sum of Ihirlj!-FD! 1r Thm 1sand Five H1 mdred Dollars($ 34 580 00 ) for the payment whereof said Principal and Surety bind themselves firmly by these presents. WHEREAS, the Principal has entered into a contract with the Obligee, dated , for MANHOLE SEALING- 2000 NOW, THEREFORE, the condition of this obligation is such that if the Principal shall perform the construction work to be done under the Contract, then this obligation shall be null and void; otherwise to remain in full force and effect. Whenever Principal shall be, and be declared by Obligee to be in default for failing to perform the construction work under the Contract, the Obligee having performed Obligee's obligations thereunder, Surety shall within a reasonable time: I. Upon entering into an acceptable written takeover agreement with Obligee, undertake to perform and complete the construction work to be done under the Contract; or 2. Obtain bids or negotiated proposals from qualified contractors for a contract for completion of the construction work to be done under the Contract, arrange for a contract to be prepared for execution by the Obligee and the contractor, to be secured with performance and payment bonds executed by a qualified surety; or 3. Waive its right to perform and complete, arrange for completion, or obtain a new contractor. 4. The Contract balance, as defined below, shall be credited against the reasonable cost of completing the construction work to be performed under the Contract. If completed by the Obligee pursuant to paragraphs 2 or 3 above, and the reasonable cost exceeds the Contract balance, the Surety shall pay to the Obligee such excess, but in no event shall the aggregate liability of the Surety exceed the amount of this bond. If the Surety completes the work pursuant to paragraph I above, that portion of the Contract balance as may be required to complete the construction work to be done under the Contract and to reimburse the Surety for its outlays shall be paid to the Surety at the times and in the manner as said sums would have been payable to Principal had there been no default under the Contract; provided, however, that to the extent that the Surety's outlays exceed the Contract balance paid to Surety by Obligee, the Surety shall be entitled to a dollar for dollar reduction of its liability under this bond, and the Surety's aggregate liability shall not exceed the penal sum of this bond. The term "Contract balance," as used in the paragraph, shall mean the total amount payable by Obligee under the Contract and any amendments thereto, less the amounts properly paid by Obligee to the Principal under the Contract. The term "construction work" as used herein shall mean the providing by the Principal of all labor and/or material necessary to complete the Principal's scope of work under the Contract. Notwithstanding any language in the Contract to the contrary, the Surety shall not be liable to the Obligee for obligations of the Principal that are unrelated to the performance of the construction work under the Contract, and the Contract balance shall not be reduced or set off on account of any such unrelated obligations, nor for any related obligations that would not be covered under this bond. 5. Any suit by the Obligee under this bond must be instituted before the earlier of: the expiration of one year from the date of substantial completion of the work, or one year after the Principal ceased performing the construction work under the Contract. If this bond is provided to comply with public works bond statutes in the location where the construction work is being performed, and the public works bond statutes contain a statute of limitations for suits on the performance bond, then the limitation period set forth herein shall be read out of this bond and the statute of limitation set forth in the public works bond statutes shall be read into this bond. If the limitation set forth in this bond is void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 6. No suit or action shall be commenced hereunder other than in a court of competent jurisdiction in the county or other political subdivision of the state in which the project, or any part thereof, is situated, or in the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. ---PAGE BREAK--- 7. This bond shall not be liable for any liability of the Principal for tortious acts, whether or not said liability is direct or is imposed by the Contract, and shall not serve as or be a substitute for or supplemental to any liability or other insurance required by the Contract. No right of action shall accrue on this bond to or for the use of any person other than the named Obligee. 8. If this bond is provided to comply with a statutory or other legal requirement for performing construction contracts for public owners in the location where the construction work is being performed, all provisions in the bond which are in addition to or differ from those statutory or legal requirements shall be read out of this bond, and all pertinent statutes and other legal requirements shall be read into the bond. Signed and sealed this 10TH SEAL TECH, INC. (Principal's name) day of Ma 2000 CONTRACTORS BONDING AND INSURANCE COMPANY By: x!tjJa , ,Attorney-in-fact ---PAGE BREAK--- t:llic INS/JRAJ'..lCE Bond Number: PB9259 Payment Bond (Public Work) Premium: For the CBIC branch nearest you, call toll free: (888) 283-2242 (888) 293-2242 FAX KNOW ALL BY THESE PRESENTS, That we, SEAL TECH INC. called the Principal, and CONTRACTORS BONDING AND INSURANCE COMPANY, a Washington corporation, called the Surety, are held and firmly bound unto CITY OF MOSCOW , called the Obligee, in the sum of Thirty-Four Thousand Five Hundred Eight and Dollars 34 580 00 ) for the payment whereof said Principal and Surety bind themselves firmly by these presents. WHEREAS, the Principal has entered into a contract with the Obligee, dated for MANHOLE SEALING - 2000 ("Contract"). NOW, THEREFORE, the condition of this obligation is such that if the Principal shall make payment to all Claimants as hereinafter defined for all labor and material used, consumed or incorporated in the petformancc of the construction work to be perfonned under the Contract, then this obligation shall be void; otherwise to remain in full force and effect, subject, however, to the following conditions: 1. A Claimant is defined as one other than the Obligee having a contract with the Principal or with a direct subcontractor of the Principal to supply labor and/or materials and said labor and/or materials are actually used, consumed or incorporated in the performance of the construction work under the Contract. 2. The above-named Principal and Surety hereby jointly and severally agree with the Obligee that every Claimant as herein defined who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the last of such Claimant's work or labor was done or perfonned or materials were furnished by such Claimant, may bring suit on this bond, prosecute the suit to final judgment for the amount due under Claimant's contract for the labor and/or materials supplied by the Claimant which were used, consumed or incorporated in the performance of the work, and have execution thereon; provided, however, that a Claimant having a direct contractual relationship with a subcontractor of the Principal shall have a right of action on this bond only if said Claimant notifies the Surety in writing of its claim within ninety (90) days from the date on which said Claimant did or performed the last labor and/or materials for which the claim is made. The Obligee shall not be liable for the payment of any costs or expenses of any such suit. 3. No suit or action shall be commenced hereunder by any Claimant: a. After the expiration of the earlier of: one year after the day on which the Claimant fast supplied the labor and/or materials for which the claim is made; or the limitation period set forth in the public works bond statutes, if any, in the location where the construction work is being petformed. Any limitation contained in this bond which is prohibited by any law controlling in the state where the suit is filed shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by the law of that state; and b. Other than in a state court of competent jurisdiction in the county or other political subdivision of the state in which the project, or any part thereof, is situated, or in the United States District Court for the district in which the project, or any part thereof, is situated, and not elsewhere. 4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith hereunder. The Surety's liability hereunder is limited, singly, or in the aggregate, to the penal sum of the bond set forth herein. 5. If this bond is provided to comply with a statutory or other legal requirement for performing construction contracts for public owners in the location where the construction work is being performed, all provisions in the bond which are in addition to or differ from those statutory or legal requirements shall be read out of this bond, and all pertinent statutes and other legal requirements shall be read into the bond. Signed and scaled this 1OTH day of May ' 2000 SEAL TECH INC. ---PAGE BREAK--- Limited Power of Attorney Home OHice: 1213 Valley Street P.O. Box 9271 Seattle, WA 98109-0271 (206) 622-7053 KNOW All MEN BY THESE PRESENTS that CONTRACTORS BONDING AND INSURANCE COMPANY, a corporation duöf organized ana existing under the laws of the State ot Washir:gton. and having its principal office in Seattle, King County. Washington, does by these presents make. constitute and appoint GAllA- of Portland, Oregon, its true and lawtui Atlorney-in-Fact, with lull power and authority hereby conferred in its name, place and stead, to execute, ac!mowledge and deliver on behatl of the Company any and all bonds and undertakings of suretyship given lor acy purpose. provided, however, that no Attorney-in-Fact shall be authorized to execute and deliver any bond or undertaking that shal! obligate the Company for any portion of the penal sum thereof in excess of $6,000,000, and provided, further, that no Attorney-in-Fact shall have the authority to issue a bid or proposal bond for any project where, ii a contract is awarded, any bond or undertaking would be required with a penal sum in excess of S 6,000,000: and to bind the Company thereby as fully and to the same extent as if such bonds were signed by the President, sealed with the corporate seal of the Company and duly attested by its Secretary; hereby ratifying and confirming all that the said Attorney-in-Fact may do in the premises. Said appointment is made under and by authority of the following resolutions adopted by the Board of Directors of the CONTRACTORS BONO!NG AND INSURANCE COMPANY on September B. 1998: RESOLVED that the President of the Company is authorized to appoint any person as the Company's true and lawful Attorney-in-Fact with power and authority to execute and deliver on behalf of the Company any and all bonds and undertaKings of suretyship given for any purpose. subject to such limits as shall be determined by the President at the Company; provided, however, that no such person shall be authorized to execute and deliver any bond or undertaking that shall obligate the Company tor any portion of the penai sum thereof in excess of $10,000,000, and provided, further, that no Attorney-in-Fact shall have the authority to issue a bid or proposal bond tor any project where, if a contract is awarded, any bond or undertaking would be required with penal sum in excess of $10,000,000. RESOLVED FURTHER that the authority ot the Secretary of the Company to certify the authenticity and effectiveness Of the foregoing resolution in any limited Power of Attorney is hereby delegated UJ t÷ following persons. the signature of any of the following to bind the Company with respect to the authenticity and effectiveness of the foregoing resolutions as it signed by the Secretary olthe Company: Donald Sirkin, StevenA. Gaines, John John A. AlKire, John D. Minto, Marc A. Mrkvicka, Lany A. Byers. Deanna Davis, Debi Lewis, Jeannie Padilla, JoAnn Johnson, Pat Dorney, and Tom Dyment. RESOLVED FURTHER that the signatures {including certøication that the Power of Attorney is still in force and effect) of the President, Notary Public and person certifying authenticity and effectiveness, and the corporate and Notary seals appearing on any Limited Power of Attorney containing this and the foregoing resolutions as well as the Limited Power of Aitomey itseif and its transmission, may be by facsimile: and such Limited Power of Attorney shall be deemed an original in ail aspects. RESOLVED FURTHER that all resolutions adopted prior to today appointing the above named as Attomey·in-Fact for CONTRACTORS BONDING AND INSURANCE COMPANY are hereby superseded. IN WITNESS WHEREOF, CONTRACTORS BONDING AND INSURANCE COMPANY has caused these presents to be signed by its President and its corporate seal to be hereto affixed this 8th day ot September, 1998. CONTRACTORS BONDING AND INSURANCE COMPANY STATE OF WASHINGTON-COUNTY OF KING On this 8th day of September, 1998, personally appeared STEVEN A. GAINES, to me known to be the President of the corporation that executed the foregoing Limited Power of Attorney and acknowledged said Limited Power of Attorney to be the tree and voluntary act and deed of said corporation, for the uses and purposes therein mentioned, and on oath stated that he is authorized to execute the said Limited Power of Attorney. IN WITNESS WHEREOE I have hereunto set my hand and affixed rny official seal the day and year first above written. OFFICW. SEAL MOLLY A. HUDSPETH NoWy Pulllic - State of W.siiHIIOn My CommtS""' E>!>m 1·9-ll The undersigned, acting u r aut rity of the Board of Directors of CONTRACTORS BONDING AND INSURANCE COMPANY, hereby certifies, as or in lieu of Certificate of the Secretary ot CONTRACTORS BONDING AND INSURANC ANY, that the above and foregoing is a full, true and correct copy of the Original Power of Attorney issued by said Company, and does hereby further certify that the said Power of Attorney is still in force and effect PoaGF01.04-US122899 ---PAGE BREAK--- May-22-00 12:55P GRABER & ASSOC INC INS 50:'!-371 5496 P.Ol ACORD. CERTIFICATE OF LIABILITY INSURANCE DATCYt 05/22/2000 Glenn R. Graber & Associates, Inc 1735 Capitol St. N.E. Salem, Oregon, 97303 SEAJ. TECH INC • 325 RD. INDEPENDENCE,OR 97351-9611 II!IS1JIU'R$ AI'FOIIDINO C0VSRAG1! -ƚ ASSURANCE CO.OF AMERICA · , · -c COLONIAL.AMI!:!'UCAi•r·c;}!SáU::.!A:;_,L"-'Tâ'f'-----l _ ,CCB#1257l6 . I A - · · · 4'iil- ƙ AN'tN./tO SCP33185214 t-v AU.ĮAUTOS Ï-Ð ĭOULft'l AUT06 SCP3378:'>214 OAI.JTOS 1 u )856 , 8-27-99 8-27-00 i 11 Ø9=-99 'TI ·9-00 • • • I• I. i • $ l!i' 001 Clt'i OF MOSCOW IS !,ISTED AS ADDITIONAL INSURED. l'T CJ'l'Y OF MOSCOW p sox 9203 MOSCOW, ID 83843-1703 $MOUI..fUlY m ,.._dOW Nl.Jali Hu.EOaeoMTd İĬ Dillt TMift!Of'. t'ME I ! t II U 1 0 OAV$ M'fW'rft !Umca 'fOllfeįTI HOLHJliiWIJO ron« 4UT.IIP f'iiolqtG 00 11M