Full Text
CONSTRUCTION CONTRACT THIS CONTRACT, dated this 3rd day of May, 2000 by and between the City of Moscow, Idaho, a municipal corporation of the State of Idaho (hereinafter 'City') and ASCORP, INC. (dba DEBCO), (hereinafter 'Contractor'): WITNESSETH: WHEREAS, pursuant to the invitation of the City, extended through an officially published "Advertisement for Bids", the Contractor did, in accordance therewith file with the City a proposal containing an offer which was invited by said notice; and WHEREAS, the City has determined that said offer was the lowest and best submitted: NOW THEREFORE, the parties to this Contract, in consideration of the mutual covenants and stipulations set out, agree as follows: ARTICLE 1. CONTRACT DOCUMENTS The Contract Documents which comprise the entire agreement between the City and the Contractor concerning the work to be performed are this Contract, pages one through four and the following: 1. Advertisement for Bids; 2. Project Specifications titled: PALOUSE RIVER DRIVE WATERMAIN • 2000 3. Bid/Proposal of the Contractor, dated April 18, 2000, to be physically attached to this Contract; 4. The Engineering Plans; 5. Performance and Payment Bonds and Insurance Certificates, to be physically attached to this contract; 6. Change Orders which may be delivered or issued after the effective date of this Contract; 7. Addenda issued prior to opening of bids. There are no Contract Documents other than those listed in Article 1. This Contract may only be amended by change order as provided in the General Conditions. ARTICLE 2. WORK The Contractor shall complete the entire work as specified, indicated and required under the Contract Documents. ARTICLE3. CONTRACT TIME I SUBSTANTIAL COMPLETION The work to be performed pursuant to this Contract shall be substantially complete within 45 calendar days from the date of the NOTICE TO PROCEED, unless adjustment of the contract time is made in accordance with the provisions of the Contract Documents. The Contractor shall begin work in conformance with the Contract Documents and shall complete the work prior to the date of completion. PAGE 1 - CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE4. CONTRACT SUM The City shall pay the Contractor for completion of the Work in accordance with the Contract Documents in current funds the amount of forty-four thousand dollars ($44,000.00). Said Contract Sum shall be paid in accordance with the Contract Documents. ARTICLE 6. INDEPENDENT CONTRACTOR The parties warrant by their signature that no employer-employee relationship is established between the Contractor and the City by the terms of this contract It is understood by the parties hereto that the Contractor is an independent contractor and as such neither it nor its employees, agents, representatives or subcontractors, if any, are employees of the City for purposes of tax, retirement system, or social security (FICA) withholding. ARTICLE&. SCOPE OF SERVICES The Contractor shall perform all services required by the Contract Documents. All work shall be completed in accordance with the plans and specifications established for this project. ARTICLE7. HOLD HARMLESS /INDEMNIFICATON In addition to other rights granted the City by the Contract Documents, the Contractor shall indemnify and save harmless the Engineer and the City, its officers and employees, from all suits, actions, or claims of any character brought because of any injuries or damages received or sustained by any person, persons, or property on account of the operations Of the Contractor or his subcontractors; or on account of or in consequence of any neglect in safeguarding the work; or because of any act or omission, neglect, or misconduct of the Contractor or his subcontractors; or because of any claims or amounts recovered from any infringements of patent, trademark or copyright; or from any claims or amounts arising or recovered under the Workmen's Compensation Act or any other law, ordinance, order or decree. ARTICLE 8. CONFLICT OF INTEREST The Contractor covenants that it presently has no interest and will not acquire any interest, direct, or indirect, in the project which would conflict in any manner or degree with the performance of its services hereunder. The Contractor further covenants that, in performing this Contract, it will employ no person who has any such interest. Should any conflict of interest arise during the performance of this Contract, Contractor shall immediately disclose such conflict to the Project Engineer I Engineer and the City. ARTICLES. ENTIRE AGREEMENT, MODIFICATION AND ASSIGNABILITY This Contract and the exhibits hereto contain the entire agreement between the parties, and no statements, promises, or inducements made by either party, or agents of either party are valid or binding unless contained herein. This Contract may not be enlarged, modified or altered except upon written agreement signed by the parties hereto. The Contractor may not subcontract or assign its rights (including the right to compensation) or duties arising hereunder other than as contemplated by the Contract Documents, without the prior written consent and express authorization of the City. PAGE 2 ·CONSTRUCTION CONTRACT ---PAGE BREAK--- ARTICLE 10. ADHERENCE TO LAW REQUIRED All applicable local, state and federal statutes and regulations are hereby made a part of this Contract and shall be adhered to at all times. Violation of any of these statutes or regulations by the Contractor shall be deemed material and shall subject the Contractor to termination of this Contract for cause. No pleas of misunderstanding or ignorance on the part of Contractor will in any way serve to modify the provisions of this requirement The Contractor and his surety shall indemnify and save harmless the City and its employees, agents and representatives against any claim or liability arising from or based on the violation of any such laws, codes, ordinances, or regulations, whether by himself, his employees, or his subcontractors. ARTICLE 11. LEGAL FEES In the event either party incurs legal expenses to enforce the terms and conditions or this Contract, the prevailing party is entitled to recover reasonable attorney's fees and other costs and expenses, whether the same are incurred with or without suit. ARTICLE 12. SPECIAL WARRANTY The Contractor warrants that nothing of monetary value has been given, promised or implied as remuneration or inducement to enter into this Contract. The Contractor further declares that no improper personal, political or social activities have been used or attempted in an effort to influence the outcome of the competition, discussion, or negotiation leading to the award of this Contract. Any such activity by the Contractor shall make this Contract null and void. ARTICLE 13. COMMUNICATIONS Such communications as are required by this Contract shall be satisfied by mailing or by personal delivery to the parties at the following address: Contractor. City: ASCORP, INC. (dba DEBCO) P.O. Box 363 Orofino, ID 83544 ARTICLE 14. EXECUTION City of Moscow 206 East Third Street P.O. Box 9203 Moscow, ID 83843 IN WITNESS WHEREOF, said Contractor and the City have caused this Contract to be executed on the day and year first above written. PAGE 3- CONSTRUCTION CONTRACT ---PAGE BREAK--- ACKNOWLEDGMENT State of \detho ) County of CCa:.:cr \ ss On this 9th day of , 2000, before me, a Notary Public of the State of _ _,l.,da , personally appeared _ and _ in their official capacity as president and secretary of ASCORP, INC. (dba DEBCO), known to me to be the persons described in the above document and acknowledged to me they executed the same. (seal) Notary Public residing at: Orofino 10 My commission expires: ses to use the following sub-contractors in the performance of meeting the contract require:rents. Info:rrration herein rrust carply with Idaho Code Section 67-2310 and IB-16: Sul:x:ontractors Trade Specialty Idaho Public Works License $ Arrotmt a. b. c. 12. 'Ibe undersigned proposes to furnish labor, materials, equiprent and services of all kinds required for PAI.OJSE RIVER llUVE - 2000 as described in the specifications, including all "l_:PJrtenant w:>rk, all as required b_y the specifications and this prop:>sal for the prices in acco:rdance with the carpleted schedule of contract prices as follows: Page 2 ---PAGE BREAK--- To the w::>rk herein specifie::l for the project entitle::l PAI.roSE RIVER rniVE A 0'0 WATERMAIN- 2000, the bidder sub:nits a lurrp sum price of $ 1'1j 000 SEAL (if incorporated) Dated at A S<:c\Z.P. J. DE'I3C..G Signature of Bidder Official Title @t?e ¹ s> A3$'1\f I L-3 Public Works License No. State of Incorporation if Incorporated This = day of (ll"- 2000. ---PAGE BREAK--- THE At\ti._,c& 'i5!(1:<4.#v ·Xf7taf:/c Name Judith C. Kaiser-Smith ķ Bond Department I FOR INFORMATION ONLY-Name, Address and Telephone) AGENT or BROKER: Wolf-Anchor-Rapp, Inc. OWNER'S REPRESENTATIVE (Architect. Engineer or P Box 2984 other party): (509) 535-9178 Spokane, WA 99220 AlA DOC UMENT A312 • PfRFORM.A)CE BONO A.'iO PAYMENT BONO· DECEMBER 1984 EO. • AlA S THE AMERICA:-: INSTITUTE OF ARCHITECTS. 1735 N(W YORK AVL. N.W WASHI:".'GTON. D.C. 10006 THIRD PRINTING • MARCH 1987 Contract 373 (12·87} A312·1984 4 ---PAGE BREAK--- 1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the perfor· mance of the Construction Contract, which is incorpo rated herein by reference. 2 With respect to the Owner, this obligation shall be null and void if the Contractor: 2.1 makes payment, directly or indirectly, for all sums due Claimants, and 2.2 Defends. indemnifies and holds harmless the Owner from claims, demands. liens or suits by any person or entity whose claim, demand, lien or suit is for the payment for labor, materials or equipment fur· nished for use in the performance of the Construction Contract, provided the Owner has notified the Contractor and the Surety (at the address described in Paragraph 12} of any claims, demands, liens or suits and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety, and provided there is no Owner Default 3 With respect to Claimants. this obligation shall be null and void if the Contractor makes pay ment, directly or indirectly, for all sums due. 4 The Surety shall have no obligation to Claimants under this Bond until: 4.1 Claimants who are employed by or have a direct contract with the Contractor have given notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice th-ereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2 Claimants who do not have a direct contract with the Contractor: .1 Have furnished written notice to the Con tractor and sent a copy, or notice thereof, to the Ovmer, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and . 2 Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above no tice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and .3 Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 5 If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety. that is suffi cient compliance. 6 When the Claimant has satisfied the conditions of Paragraph 4, the Surety shall and at the ··Surety's expense take the following actions: 6.1 Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2 Pay or arrange for payment of any undisputed amounts. 7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the perfor mance of the Construction Contract and to satisfy claims, if any, under any Construction Performance Bond. By the Contractor furnishing and the Owner accepting this Bond. they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's prior ity to use the funds for the completion of the work. 9 The Surety shall not be liable to the Owner. Claimants or others for obligations of the COntractor that are unrelat ed to the Construction Contract. The Owner shall not be liable for payment of any costs or expenses of any Claim ant under this Bond. and shall have under this Bond no obli gations to make payments to. give notices on behalf of. or otherwise have obligations to Claimants under this Bond. 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. 11 No suit or action shalf be commenced by a Claimant under this Bond other than in a court of competent juris diction in the location in which the work or part of the work is located or after the expiration of one year from the date on which the Claimant gave the notice required by Subparagraph 4.1 or Clause 4 23. or on which the last labor or service was performed by anyone or the last mate rials or equipment were furnished by anyone under the Con struction Contract. whichever of or first occurs If the provisions of this Paragraph are void or prohibited by la>v . the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished. shall be sufficient compliance as of the date received at the address shown on the signature page. 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed. any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions con forming to such statutory or other legal requirement shall be deemed herein_ The intent is that this AlA DOCUM£NT AJ12 • PERFORMASCf BOIO At-.;0 PAYMENT BOSD" DECEMBER 198-t (0 TH( AMERICAN INSTITUTE OF ARCHITECTS. 1735 YORK AVE. W. WASH!NCTO"', D C THIRD PRINTING • MARCH 1987 A312-1984 5 ---PAGE BREAK--- Bond shall be construed as a statuto!)' bond and not as a common law bond. 14 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor shall furnish a copy of this Bond or shall permit a copy to be made. 15 DEFINITIONS 15.1 Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equip· ment for use in the performance of the Contract. The intent of this Bond shall be to include without limita tion in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the MODIFICATIONS TO THIS BOND ARE AS FOllOWS: Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor"s subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.1 Construction Contract: The agreement between the Owner and the Contractor identified on the sig nature page, including all Contract Documents and changes thereto. 15.3 Owner Default: failure of the Owner, which has neither been remedied nor v ,aived, to pay the Con· tractor as required by the Construction Contract or to perform and complete or comply vvith the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPr.L Company: (Corporate Seal) SURETY Company: (Corporate SeaiJ Signature: Name and Title: Name and Title: Address: Address: AlA DOCUMENT A3l2 • PERFORM.-\f'..:(( BONO A:-.i:D PAYME:--IT BONO· DECEMBER 19ʧ W. ·AlA S THE AMERICAN INSTITUTE OF ARCH!TEC1S. 1735 N[W YORK AVE N.W D.C. 20006 THIRD PRL-..;T!NC • MARCH 1987 A312·1984 6 ---PAGE BREAK--- Pmn:r of i\.ttorney ?\io. POWER OF ATTOR:'>EY Seaboard Surety Company St. Paul Fire and :Vlarine Insunmcc Company St. Paul Guardian In.surtmce Company St. Paul MNYm·y lnónrara:e Company 21726 Lnited States Fidelity and Guaranty Company Fkldity and Guaranty lnsuram·t· Company Fidelity and Guaraut:v Insurance Cndenvdters, inc. KNOW ALL B'l THESE PRESE:'\TS: T!ut Sc;aboard Sun:ry Company is w "{ork. nlt:Kh :md <:.\l'<:tHing or purantccing b,md.` in -¯!ny acli\ms or proceedings ai!mvcd hy bw Stak of Maryland City of JLltinwrc Jay oj April 2000 · . , , States Fiddity and Guuranty Company Fidelity and Guaranty insurance Company Fidelity and Guaranty lnsurancc !}nderwriii.'n,, Inc. J( ll I. v:ʦc· !-'r,>ickni On this 11th day April 2000 . before me. the unJehiJ.!nc-d officer. ;qpcar..:d Jib; :\nd Ih CIS dnly awhori!<:d officer\ L:\Si.E'(CV\(JL\L Pu>!i, ---PAGE BREAK--- Af PRODUCER WOLF ANCHOR·RAPP. INC. E 40_;5 3ROADWAY P 0 BOX 2984 SPOKANE l\.SCORP INC U3A DE3CC PO DOX 363 OROFINO l'1A 99220- ID 83544- COMPANY A COMPANY B COMPANY c COMPANY 0 THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD lND!CATED, NOTWiTHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. co LTR TYPE OF INSURANCE A GENERAl UABIUTY POLICY NUMBER X COMMERC!ALGENERALUABILITY C06 12 93 03 - ClAiMS MADE :X OCCUR OWNER'S & CONTRACTOR'S PROT' X AGGREGATE PER PROJECT A AUTOMOBilE LIABILITY X ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HiRED AUTOS NON"OWNED AUTOS GARAGE UABIUlY ANY AUTO A EXCESS LIABILITY A X UMBRELLA FORM WORKERS COMPENSATION AND EMPLOYERS' LIABILITY CARGO COVERAGE C06 12 93 03 ECL 16100 C06 12 93 03 WA STOP GAP C06 12 93 03 RE, PALOUSE RIVER DRIVE WATERMAIN REPLACEMENT 2000 i POUCY EFFECTIVE . DATE 06/18/99 06/18/99 I 06/18/99 06/18/99 01/19/00 06/18/00 06/18/00 I I 06/18/00 06/18/00 06/18/00 LIMITS $ PROPERTY DAMAGE S ) EACH _9CCURRENCE AGGREGATE 000, 000 • _ 0 0 0 MOTOR TRUCK CARGO 300,00C! CITY OF MOSCOW, IDAHO IS NAMED AS ADDITIONAL INSURED AS RESPECTS WORK PERFORMED ON TI!EIR BEHALF BY NAMED INSURED LiNDER CONTRACT CITY OF t'I:.OSCOW P.O. BOX 9203 V.OSCOW ID 83843 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILLKL MAIL _lQ_ DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT. ---PAGE BREAK--- C06-12-93-u3 DEB CO 06/18/99 COMMERCIAL GENERAL LIABILITY cs 807 (8-97) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. AUTOMATIC ADDITIONAL INSUREDS INCLUDING COMPLETED OPERATIONS TO THE EXTENT REQUIRED BY AN INSURED CONTRACT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART The following is added to WHO IS AN INSURED (Section II): 1. To the extent it is required by the terms of an "insured contract" which requires you to add by endorsement as an additional insured a person or organization, WHO IS AN INSURED (Section II) is amended to include as an insured such person or organization ("additional insured") but only with respect to: Vicarious liability arising out of your ongoing operations performed for the additional insured; or Liability arising out of any act or omission of the additional insured for which you have entered into an enforceable "insured contract" which obligates you to indemnify the additional insured, or to furnish insurance coverage for the additional insured, and arising out of your ongoing operations for that additional insured. With respect to the insurance afforded these additional insureds, the following additional exclusions apply: 2. This insurance does not apply to "bodily injury," or "property damage" occurring after: All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs), to be performed by or on behalf of the additional insured(s) at the site of the covered operations has been completed; or That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. This exclusion does not apply to the extent that an "insured contract" requires that you assume the tort liability . of the additional insured arising out of a risk that would otherwise be excluded by this exclusion. 3. This insurance does not apply to: "Bodily injury," "property damage," "personal injury" or "advertising injury" arising oul of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including: The preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; and Supervisory, inspection, architectural or engineering activities. Includes copyrighted material of Insurance Services Office, Inc., with its permission. NORTH PACIFIC INSURANCE COMPANY cs 807 (8-97) Page 1 of 2 ---PAGE BREAK--- 1215 W. STATE STREET - PO BOX 83720 - BOISE, IDABO 83720-0044 PHONE (208) 332-2100 - (800} 334-2370 AGENT: 89 CERTIFICATE HOLDER: 295019 C I TY OF MOSCOW PO BOX 9203 WALRATH I NSURANCE AGENCY I NC PO BOX 788 MOSCOW 1 0 83843-3002 OROF I NO 1 0 83544-0000 208/476-5527 CERTIFICATE OF WORKERS COMPENSATION INSURANCE The State Insurance Fund hereby certifies that the i nsurance pol i cy hereunder described i s i n fu l l force and effect on the date of this certificate and that i t remains i n fu l l force and effect unti l cance l l ed . POLICY NUMBER: 534766 INSURED: ASCORP PO BOX 363 OROFINO ID 83544-0000 ORIGINAL EFFECTIVE DATE: 07/19/1991 MISCELLANEOUS : RE : PALOUSE RIVER DRIVE WATER MAIN PROJECT # 102-00 Pol i cy in force from 07/19/1991 12: 01 a.m. , Mountai n Standard Time, at the address of the insured shown above or the job site i n Idaho. PART TWO: EMPLOYERS LIABILITY I NSURANCE LIMITS Bod i l y Injury by Accident $100,000 each accident Bod i l y Injury by Di sease $500,000 pol i cy l imit Bod i l y Injury by Disease $100,000 each employee The i nsurance coverage appl i e s to employees of the above-menti oned company anywhere i n the state of Idaho and a l so to any employees l i v i ng i n Idaho but working temporarily in a neighboring state. In addition to the requ ired coverage, tne fol l owing e l ected coverage a l so appl ies: Lonn i e E Simpson Corporate Officer Shannon Simpson Not Exempt Offi cer This certifi cate i s val i d for one year from date of certificate. In the event of cance l l ation of said pol i cy, the State Insurance Fund wi l l endeavor to notify the party to whom this certificate is issued by providing ten (10) days advance noti ce , but the State Insurance Fund shal l not be l i able in any way for fai l ure to give noti ce . Dated at Boi se, Idaho on May 5 , 2000 Marcy Pau l s Underwriting 208/332-2313 Servi ce ions Department Coeur d' AJene HJO(} W Hubbard Stnn;t Harbor C&nter, Suit!'! 100 COGUf d' Aitne, fD 153814 208!76f F 1 5 t 3 Lewiston 1 1 F PocateHo 383 North 4th, Suit& 2SO F\(L Box 2228 lD 33206 iwtn Falls Rd !D 83301 ldahc Fans 525 i"Mk Suite 2C Idaho !0 83402 ---PAGE BREAK--- WOLF - fu'JCHOR--RAPP, INC. E 4 0 0 5 BROADWAY P 0 BOX 2984 SPOKANE ( 5 0 9 ; 5 3 5 9 1 INSURED ASCORP INC DBA DEBCO PO BOX 3 6 3 OROFINO WA 9 9 2 2 0 - I D 8 3 5 4 4 - COMPANY A NORTH PACIFIC INSU'JCE CO COMPANY B COMPANY c COMPANY D THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. CO I POLICY NUMBER TYPE OF INSURANCE LTR ' A g-MNERAL UABILITY X ' COMMERCIALGENERAL UABIUTY C07 1 2 93 0 3 A A j CLAIMS MADE OWNER'S & CO>JTRI,CT•JR'E; PROT! LIABILITY ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS THE PROPRIETOR! PARTNERS/EXECUTIVE OFFICERS ARE A OTHER CARGO COVERAGE C07 12 9 3 0 3 ECL 1 8 1 2 6 C O ? 1 2 9 3 0 3 WA STOP GAP C07 12 93 0 3 OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS RE: PALOUSE RIVER DRIVE WATERMAIN REPLACEMENT 2 0 0 0 I POLICY EFFECTIVE , DATE {MM/DO!YY) LIMITS ! GENERAL AGGREGATE , " . $ 2 , ·)00 CCC 0 6 / 1 8 / 0 0 0 6 / 1 8 / 0 1 0 6 / 1 8 / 0 0 0 6 / 1 8 / 0 1 I I I I 06/18/00 0 6 / 1 8 / 0 1 06/18/00 0 6 / 1 8 / 0 1 06/18/00 06/18/01 MOTOR TRUCK CARGO 3 0 0 , 0 0 0 CITY OF MOSCOW, IDAHO IS NAMED AS ADDITIONAL INSURED AS RESPECTS WORK PERFORMED ON THEIR BEHALF B Y NAl"'lED U!-lDER CONTRACT CITY 0? MOSCOW P . O - BOX 9 2 0 3 XOSCOW ID 8 3 8 4 3 SHOULD ANY O F THE ABOVE DESCRIBED POliCIES B E CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY