Full Text
CITY OF MOSCOW TO Item No. Quotation Reference Date Quantity The to 83704 CITY OF MOSCOW MOSCOW, IDAHO PURCHASE ORDER rnc. Description INSTRUCTIONS This order authorizes your firm to ship the items listed below, or perform the service requested in accordance with specified con# ditions. DATE N? 2872 Requisition No. Per Unit Amount March • • t to carry all the insurances City ha from worl\ma ship • a period of o e year. Purchasing Agent l 271. 25 96-Jo ---PAGE BREAK--- NORTHWEST,TECHNOLOG/ES INC. 208/323-0757 1/800/657-1087 March 5, 1996 Engineering Office City Hall Annex 122 E. 4th Street P.O. Box 9203 Moscow, ld 83843 GENERAL CONSTRUCTION 6724 EMERALD STREET BOISE, IDAHO 83704 RE: Renovating the paint on the First Floor Exterior Doorways of City hall Building At Third and Washington Dear Gentlemen: Northwest Technologies, Inc., proposes to remove lead based paint and repaint the exterior doorways at the above referenced location as per specifications for the Lump Sum of $10,850.00. If bonding is required, add 2.5% to the bid price. This bid includes all licenses and fees, all other insurances, materials, labor, taxes and disposal costs. All work will be completed in accordance with all State of Idaho, NESHAPS, DEQ, and OSHA regulations. This bid is valid for thirty days. If you have any questions, please give me a call. Sincerely, cI"'\ DAVID L. HOLMAN President DLH/TLB ---PAGE BREAK--- NORTHWEST TECHNOLOGIES INC. 208/323-0757 1/800/657-1087 March 5, 1996 GENERAL CONSTRUCTION Qualifications for lead paint removal: 6724 EMERALD STREET BOISE, IDAHO 83704 Northwest Technologies has been in the hazardous waste business for 7 years. The company has completed lead paint removal projects for business such as: • Mountain Home AFB • Gowen Field ANG Base • Ada County Highway Dept. • Albertson's College • St. Lukes Hospital References and descriptions of these projects can be furnished upon request Six employees of NWTech have lead supervisor training and have experience on working on lead projects. NWTech plans to isolate the work area. Utilize a product named PEEL-AWAY for the removal. The surface as well as the waste material will be neutralized after removal. After the waste is containerized, it will be shipped by a hazardous waste carrier and disposed of at the Envirosafe waste site located in Grandview, Idaho. Documenl2 ---PAGE BREAK--- IDAHO STATE INSURANCE FUN!:: DREW S. FORNEY MANAGER 1215 W< STATE STREET - PO BOX 83720 - BOISE, IDAHO 83720-<>044 PHONE (208J 334-2370 - (800) 334-2370 PHILIP BATT GOVERNOR ISSUED TO: CITY OF MOSCOW PO BOX 9203 MOSCOW, 10 83843-1703 CERTIFICATE OF INSURANCE PROJECT: CITY HALL BUILDING The State Insurance Fund hereby certifies that the insurance policy hereunder described is in full force and effect on the date of this certificate and that it remains in full force and effect unt1l canceled. NAME(S) OF INSURED: NORTHWEST TECHNOLOGIES INC MAILING ADDRESS OF INSURED: 6724 EMERALD ST BOISE, ID 83704 Policy in force from 7/10/89 12:01 a.m., standard time at the address of the insured shown above or the job site in Idaho. Type of Insurance Workers Compensation Occupational Disease Employer's Liability Limits: Bodily injury by Accident - Bodily injury by Disease - Bodily injury by Disease - Policy Number 527914 $100,000 each accident $500,000 policy limit $100,000 each employee Coverage Subject to the terms of the Workers Compensation Laws and Occupational Disease Laws of the State of Idaho. The insurance coverage applies to employees of the above-mentioned company working anywhere in the state of Idaho and also to any employees living in Idaho but working temporarily in a neighboring state. In addition to the required coverage, the following elected coverage also applies: This certificate is valid for one year from date of certificate. In the event of cancelation of said policy, the State Insurance Fund will endeavor to notify the party to whom this certificate is issued by providing ten (10) days advance notice, but the State Insurance Fund shall not be liable in any way for failure to give such notice. s;hq: _ · · · Robert H. Creighton Underwriting Manager SIF 00204 U8CHARLOTTE P20360201 Coeur d'Aiene 2005 ironwood Swite 227 lewiston '1118 Strnet :c 83501 Pocatello 353 North 4th, Suiw 280 P.O. Box 2228 Twin Falls Idaho Falls 525 Psrk Avenue Suits 2C Coeur iD ̚3514 lD 83206 Twin iD 83301 D 83402 ---PAGE BREAK--- 03127/199& 15̙16 [PHONE REDACTED] X B X X A X c POST INSURANCE SERVICES P.O. BOX 8447 4477 eMERALD ST. #A-200 BOISE, lD 83707 Nonllwest Teclioologies 1m; 6724 Emerald BoW..ED 83704 Tl'P£ OF CLAiMS MAOJ!- X· occo• · OWNfR"S & CONtit:ACfOR,S J"AOT. i\NYAV'TO ALL OWNF.D iW'fO$ AU'ro5 HikED AUTOS . NON.o\\'NED A!JI'O$ OAAACi Uliotmt6t.LA FOR:M ̕THAN VMBREttA FOKM WOJtK!lt'S COMPENSATION - DtFLO\'Jm$' UABlUTY ASBESTOS LIABILITY l'OLICY-· Cl'P 20422HJ3 BA 2!978650 CU930807 AaC95l30!426 RE: CITY HALL BUILDING ON 3RD CITY OF MOSCOW 1'0 BOX 9203 MOSCOW, ED 83843 14=22 TECH PAGE 02 COMPANIES AFFORDING Cov:EltAGE COLORADO CASUALTY INS. CO. SAFECO INSURANCE COMPANY FIDELITY ENVIRONMENTAL POUC\" JJnE:C'l'IV£ _ POUCi £XPI:R..t11QN llA'TE {MWl)b!YY) 09128195 02101196 09128195 ll!!l/95 DA1£̖: 09128!% 0210!197 09128196 !Iilli% PROJ>tlC"r$.COMPIOP ,.\GGR< : PSilSOHM.. &A'DV_ INiuaY J!A(H: OCCLIRJtaief: · ARE DAMAGS (My .0116 D. UM11 f;J()DU. Y INIUU . · 9000.-\' INJURY ̓ (1\T ̔idul; '̘YDAMAG2 · . · • • 0 !ACNACCIDEN'f DISf!ASIN'OUCY liMIT -̗EA('ii :occURRENCE AGGREGATE ' ' $ $ ' ' ' • ' ' ' ' ' ' 1,000,000 1,000,000 1,000,000 50,000 !,000,000 1,000,000 !.000,000 SHOill.O ANY OP 1HE ABOVE .PESCIUBED BE CANCELLED BE-FORE THE DATll Tl!EilEOF, TilE ISSUING COM!' ANY WilL ENOEA VOlt TO MAll DAYS W1.UTrEN NOnCE TO THE CERTIFICATE HOLDEk NAMED TO TilE" LEFT. BUT PAilUR.!l TO MAlL SUCH NOTICE Sl!AU.lMPOSS NO OBUGA'tlON OR UA.Btur¥ OF ANY KIND UPDN THE COMf'ANY, ITS AGENT$ OR REPRESENTATIVES' P.02 ---PAGE BREAK--- VONT!CELLO. NE'N YORK 'A StocK Comparly} THE AMERICAN INSTITUTE OF ARCHITECTS AlA Document A312 Performance Bond 89334 No. Any srngular reference to Contractor, Surety. Owner or otrer party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Pnncipal Place of Business): NORTffiifEST TECHNOLOGIES, INC. 6724 EMERALD ST. BOISE, ID 83704 OWNER (Name and CITY OF MOSCOW P.O. BOX 9203 MOSCOW, ID 83843 CONSTRUCTION CONTRACT Date 3/18/96 FRONTIER INSURANCE COMPANY 195 LAKE LOUIS MARIE RD. ROCK HILL, 12775-8000 Amount ELEVEN THOUSAND, ONE HUNDRED TWENTY-ONE & .25/100ths------($11,121. (Name and Locatron): FIRST FLOOR DOORWAYS RENOVATION CITY HALL BUILDING, 206 E. THIRD BOND Date (Not earlier :han Construction Contract Date): 3/21/96 Amount ELEVEN THOUSAND, ONE '{UNDRED TWENTY·-ONE & • 25/100ths---- ( $11, 121 . 25) Modifications to this Bond: CONTR'-CTOR AS PRINCIPAL NORTffiifEST . OLOGIES, INC. (Corporate Seal) I \ r\ Signature: Name and Title: (Any additronal srgnatures appear on page 3) XX¾JONE SURETY FRONTIER (Corporate Signature: Name and {FOR INFORMATION ONLY -Name. Address and Telephone! 0 See Page 3 AGENT or BROKER: OWNER'S REPRESENTATIVE Engtneer or CASCADE SURETY & BONDING, INC. other party): 19009 33rd Ave i-1, 11310 WA. 98036 PRiNTED !N COOPERATION WITH THE AMERiCAN ,NSTiTUTE OF ARCHiTECTS iAIA) BY THE FRONTiER INSURANCE COMPANY, irlE LANGUAGE iN THiS DOCUMENT <::ONFORMS EXACTLY TO TrlE LAN· GUAGE USED iN A:A DOCUMENT A302, DECEMBER, -:984 EOIT:mJ. THIRD PRINTiNG, MARCH. 1987 FM 19-'194An2;92) A312-1984 1 ---PAGE BREAK--- 1 The Contractor and the Surety. jointly and severally, bind themselves, their heirs, executors. admmistrators, succes sors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shaii have no obligation under this Bond, except to participate in conferences as provided in Subparagraph 3.1 3 If there is no Owner Default the Surety·s obligation under this Bond shall arise after: 3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below that the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss meW thods of performing the Construction Contract If the Owner, the Contractor and the Surety agree, the Contrac tor shall be allowed a reasonable time to oeriorm the Construction Contract, but such an agreement shall not waive the Owner's right. if any, subsequently to declare a Contractor Default and 3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor Default shaH not be declared earlier than twenty days after the Contractor and the Surety have received notice as prov1ded in Subparagraph 3.1; and 3.3 The Owner has agreed to pay the balance of the Contract Price to the Surety in accordance with the terms of the Construction Contract or to a contractor selected to perform the Construction Contract in accordance with the terms of the contract with the Owner. 4 When the Owner has satisfied the conditions of Paragraph 3. the Surety shall and at the Surety's expense take one of the following actions: 4.1 Arrange for the Contractor, w1th consent of the Owner. to perform and complete the Construction Con tract: or 4.2 Undertake to perform and complete the C('f!Struction Contract itself, through its agents or through independent contractors: or 4.3 Obtain bids or negotiated proposais from qualified contractors acceptable to the Owner for a contract for performance and completion of the Constructon ConW tract. arrange for a contract to be prepared tor execution by the Owner and the contractor seiected with the Owner's concurrence. to be secured with performance and payment bonds executed by a qualified surety equiƇ valent to the bonds issued ,';r1 the Construction Contract, and pay to the Owner the amount of damages as de scribed in Paragraph 6 in excess of the Balance ot the Contract Price incurred by the Owner resulting from the Contractor's default or 4.4 Watve its right to perform and complete, arrange for completion, or obtain a new contractor and with reasona ble promptness under the circumstances: . 1 After investigation, determme the amount tor which it may be iiabie to the Owner and, as soon as practicable after the amount is determined, tender payment therefor to the Owner; or .2 Deny liability in whole or in part and notify the Owner citing reasons therefor. 5 If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness. the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the Owner to the Surety deW manding that the Surety perform its obligations under this Bond, and the Owner shaH be entitled to enforce any remedy available to the Owner. It the Surety proceeds as provided in Subparagraph 4.4, and the Owner refuses the payment ten dered or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 6 After the Owner has terminated the Contractor's right to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1, 4.2. or 4.3 above, then the responsibilities of the Surety :o tr;e 0'>vne; shall net be great er than those of the Contractor under the Construction Con tract, and the responsibiiities of the Owner to the Surety shall not be greater than those of the Owner under the Construeƈ tion Contract. To the limit of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Surety IS obligated without dupli cation for; 6.1 The responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; 6.2 Additional legaL design professional and delay costs resulting from the Contractor's Oefauit and resulting from the actions or failure to act ofrhe Surety under Paragraph 4;and 6.3 Liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor_ 7 The Surety shall not be liable to the Owner or others for obiigations of the Contractor that are unrelated to the Con struction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shaH accrue on this Bond to any person or entity other than the Owner or its heirs. executors. administrators or successors. 8 The Surety hereby waives notice of any change, mcluding changes of time. to the Construction Contract or to reiated subcontracts. purchase orders and other obligations. 9 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or oart of the work is iocated and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under th1s Bond. whichever occurs first. If the provisions of this Paragraph are void or prohibited by law. the minimum period of !imitation available to sureties as a defense in the jurisdiction of the suit shail be applicable . PRINTED IN COOPERATiON WiTH THEAMEP'CAN l!'iST!TUTE OF ARCHITECTS (AiAl BY THE FRONTIER COMPAt'clY_ THE LANGUAGE :N THIS DOCUMENT CONFORMS EXACTLY TO THE LAN GUAGE JSED !N AlA DOCUMENT A312. DECEMBER., 1984 EDITION. THIRD PRiNTiNG. MARCH, 1987 A312-1984 2 FM ø9-1194Ai12/92) ---PAGE BREAK--- Jjj/ . WlBT INSURANCE COMPANY MONTiCElLO, NEW YORK (A Stock Company) THE AMERICAN INSTITUTE OF ARCHITECTS AlA Document A312 Payment Bond 89334 No. Any smgular reference to Contractor. Surety. Owner or other party shall be considered pi ural where applicable. CONTRACTOR (Name and Address): NORTHWEST TECHNOLOGIES, INC. 6724 EMERALD SURETY (Name and Principal Place of Business): BOISE, IDAHO 83704 OWNER (Name and Address): CITY OF MOSCOW P.O. BOX 9203 MOSCOW, ID 83843 FRONTIER INSURANCE COMPANY 195 LAKE LOUIS MARIE RD. ROCK HILL, 12775-8000 CONSTRUCTION CONTRACT Date 3/18/96 Amount ELEVEN THOUSAND, ONE HUNDRED TWENTY-ONE & .25/100ths----($11,12l.25)---- (Name and Location): FIRST FLOOR DOORWAYS RENOVATION, CITY HALL BUILDING, 206 E THIRD BOND Date (Not earlier than Construction Contract Date): 3/21 I 96 Amount: ELEVEN THOUSAND, ONE HUNDRED TWENTY-ONE & 25/100ths---(Sll,J21.25)----··- Modifications to this Bond: [l;J NONE 0 See Paqe 3 CONTRACTOR AS PRINCIPAL SURETY TECHNOLOGIES, INC. (Corporate Seal) FRONTIER INSU8,'\NCE COMPANY (Corporate Seal) · Signature: Signature: Name and Title: Name and Attorney-in-Fact (Any addit;onal Signatures appear on page 3) !FOR INFORMATION ONLY5Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect Engineer or CASCADE SURETY & BONDING, INC. other party): 19009 33rd Ave W, #310 LYNlVOOD, WA 98036 PRINTED lN COOPERATiON WITH THE .A.MERICAN INSTiTUTE OF ARCHiTECTS ;AlA) BY THE FRONTIER iNSURANCE COMPAI'-.iY, THE LANGUAGE iN TH!S DOCUMENT CONFORMS EXACTLY TO THE LAI'--J+ GUAGE USED !N AiA DOCUMENT A312, DECEMBER. :984 EDiTiON. THIRD P81NTiNG. MARCH, 1987 FM 19-1195A A312-1984 4 ---PAGE BREAK--- 10 Notice to the Surety, the Owner or the Contractor shaH be mailed or delivered to the address shown on the signature page. 11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12 DEFINITIONS 12.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Con struction Contract after all proper adjustments have been made, including allowance to the Contractor of any MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 12.2 Construction Contract: The agreement between the Owner and the Contractor identified on the siQnature page, including all Contract Documents and changes thereto. 12.3 Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract. 12.4 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL (Corporate Seal) SURETY FRONTIER INSURANCE COMPANY (Corporate Seal) Signature: Name and Title: Signature: Name and Title: Address: Address: PAINTED IN COOPERATION WITH THE AMERICAN INSTITUTE OF ARCHITECTS (AlA) BY THE FRONTIER INSURANCE COMPANY_ THE LANGUAGE IN THIS DOCUMENT CONFORMS EXACTLY TO THE LAN) GUAGE USED IN AlA DOCUMENT A312. DECEMBER, 1984 EDITiON, THIRD PRINTING, MARCH, 1987. FM 19̎1194A{12!92) Countersigning Agent A312-1984 3 W·5228·12192-2M ---PAGE BREAK--- 1 The Contractor and the Surety, jointly and severally, bind themse·lves, their heirs, executors, administrators, succes sors and assigns to the Owner to pay for labor, materials and equipment furnished tor use in the performance of the Con struction Contract which is incorporated herein by reference. 2 With respect to the Owner. this obligation shall be null and void if the Contractor: 2.1 makes payment. directly or indirectly, for all sums due claimants, and 2.2 Defends. indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity whose claim, demand, lien or suit is for the payment for labor. materials or equipment furnished for use in the performance of the Construction Contract, provided the Owner has notified the Contractor and the Surety (at the address described in Paragraph 12) of any claims. demands. liens or suits and tendered defense of such claimS, demands, liens or suits to the Contractor and the Surety, and provided there is no Ow nor Default. 3 With respect to Claimants, Hlis obligation shai! be null and void if the Contractor makes payment, directly or :ndirectly, for ali sums due. 4 The Surety shall have no obligation to Claimants under this Bond until: 4.1 Cla:mants who are employed by or have a direct contract w1th the Contractor have given notice to the Surety (at the address described ;n Paragraph 12) and sent a cooy, or notice thereoL to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy. the amount of the cla1m. 4.2 Claimants wno do not have a direct comract with the Contractor: . Have furnished written notice to the Contractor and sent a copy, or notice thereof, to the Owner. within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the cla1m and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed: and .2 Have e:ther received a rejection in whole or in part from the Contractor, or not received Within 30 days of furnishing the above notice any communiw cation from the Contractor by which the Contractor has indicated the claim will be paid directly or indi rectly: and . 3 Not having been paid within the above 30 days. have sent a written notice to the Surety (at the ad dress described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a c!aim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 5 If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety, that is sufficient compli ance. 6 When the Claimant has satisfied the conditions of Para graph 4. the Surety shall and at the Surety's ex pense take the following actions: 6.1 Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challeng ing any amounts that are disputed. 6.2 Pay or arrange for payment of any undisputed amounts. 7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any. under any Construction Performance Bond. By the Contractor fur nishing and the Owner accepting this Bond, they agree that a !I funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. 9 The Surety shall not be iiabie to tr.e Owner, C1a1rnanis or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to. give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10 The Surety hereby waives notice of any change, includƉ ing changes of time. to the Construction Contract or to relat ed subcontracts, purchase orders and other obligations. 11 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdicƊ tion in the location in which the work or part of the work is located or after the expirat1on of one year from the date on which the Claimant gave the notice required by Subpara graph 4.1 or Clause 4.2 (iii), or on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construc tion Contract. whichever of or first occurs. If the provi sions of this Paragraph are void or prohibited by law. the minimum period of limitation available to sureties as a de fense in the jurisdiction of the suit shall be applicable. 12 Notice to the Surety. the Owner or the Contractor shall be mailed or delivered to the address shown or the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished. shall be sufficient com pliance as of the date received at the address shown on the signature page . 3 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed. any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other iegal requirement shall be deemed incorporated herein. The intent 1s that this Bond shall be construed as a statutory bond and not as a common law bond. 14 Upon request by any person or entity appearing to be a potential beneficiary of this Bond. the Contractor shall furnish a copy of this Bond or sha!i permit a copy to be made. PRiNTED !N COOP ERA T!ON WITH THE AMERiCAN INSTITUTE OF ARCHiTECTS iAIA) BY THE FRONTiER iNSURANCE COMPANY THE LANGUAGE !N THIS DOCUMENT CONFORMS EXACTLY TO THE LAN GUAGE USED iN AlA DOCUMENT A3"12. DECEMBER. 1984 EDITION, THIRD PRINTiNG, MARCH. 1987 A312-1984 5 FM 19-1195Ai12!92) ---PAGE BREAK--- 15 DEFINITIONS 15.1 Claimant An individual or ent1ty hav1ng a direct conl tract with the Contractor or with a subcontractor of the Contractor to furnish labor, matenais or equipment for use 1n the periormance of the Contract. The intent of thiS Bond shall be to include w1thout limitation in the terms '·labor. matenals or equipment" that part of water. gas, power. light, heat oiL gasoline. telephone serv1ce or rentai equ1pment used in the ConstructiOn Contract architectu ral and engineering serv1ces reqLnred for performance of the work of the Contractor and the Contractor's subcon tractors, and all other items for which a mechanic's iien MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: may be asserted in the JUfiSdiction where the !abor, mate rials or equ1pment were furn1shed. 15.2 Construction Contract The agreement between the Owner and the Contractor identified on the s:gnature page, mcluding ail Contract Documents and changes thereto. 15.3 Owner Defauit Failure of the Owner. which has ne1ther been remed1ed nor wa1ved. to pay the Contractor as requ1red by the ConstructiOn Contract or to perform and complete or comply w1th the other terms thereof (Space is provided below for additional Signatures of added parties. other than those appeanng on the cover page.) CONTRACTOR AS PRINCIPLE (Corporate Seal) Signature: Name and Title: Address: SURETY FRONTIER INSURANCE COMPANY (Corporate Seal) Name and Title: Address: Countersigning Agent PRINTED IN COOPERATION WITH THE AMERICAN lNST:TUT!: OF ARCHITECTStAIAl BY THE FRONTIER INSCRANCE COMPANY. THE !...ANGUAGE :N THIS DOCUMENT CONFORZ 1S EXACTLY TO THE LAN GUAGE USED iN AiA DOCUMHJT A312, DECEMBER "1984 ED!T!ON. THiRD PRINH JG. MARCH. '987 A312-1984 6 ---PAGE BREAK--- 0 TD/Iller INSURANCE coMPANY ROCK HILL, NEW YORK 12775-8000 iA Stock Company) POWER OF ATTORNEY Bond No.89334 1!:hwtu All Jiit'll f!Ju [lIt'Sl' lJn''iH'nts; That FRONTIER INSURANCE COMPANY a New York Corporation, having 1ts principal office in Rock Hill. New York. pursuant to the following resolution. adopted by the Board of Directors of the Corporat1on on the 4th day of November. 1985: "RESOL VEO, that the Chairman of the Board. the President, 01 any Vice President be_ and hereby is. authorized to appoint Attorneys-in Fact to represent and act for and on behalf of the Company to execute bonds. under!akmgs. recognizances and other contracts of indemnity and writings obligatory in the nature thereof, and to attach thereto the corporate seal of the Company. in the transaction of its surety business: ··RESOLVED, that the signatures and attestations of such officers and the seal of the Company may be affixed to any such Power of Attorney or to any certificate relating thereto by facs1mile. and any such Power of Attorney or certificate bearing such facsimile signatures or facsimile seal shall be valid and bind1ng upon the Company when so affixed w1th respect to any bond, undertaking. recognizance or other contract of indemn1ty or writing obligatory in the nature thereof: "'RESOLVED. that any such Attorney-m·Fact delivering a secretarial certification that the forego;ng resolutions stiH be in effect may insert in such certification the date thereof. said date to be not later than the date of delivery thereof by such AttorneyÔin-Fact"' This Power of Attorney is signed and sealed in facsimile under and by the authority of the above Resolution DOES HEREBY MAKE CONSTITUTE AND APPOINT Gordon Wibbens Jerilyn Wibbens of Seattle . in the State of Washington its true and lawful Attorney(s)-in-Fact w1th lui! power and authority hereby conferred 1n its name. place and stead to sign, execute, acknowledge and deliver in its behalf. and as its act and deed, without power of rede!egation. as follows Bonds guaranteeing the fidelity of persons ho!ding places of public or private trust: guaranteeing the performance of contracts other than insurance policies; and executing or guaranteeing bonds and undertakings required or permitted in all actions or proceedings or by law allowed; IN AN AMOUNT NOT TO EXCEED THREE MILLION FIVE HUNDRED THOUSANDt$3,500,000,00) DOLLARS; and to bind FRONTIER INSURANCE COMPANY thereby as fully and to the same extent as if such bond or undertaking was signed by the duly authorized officers of FRONTIER INSURANCE COMPANY. and a !I the acts of said Attorney(s)-in-Fact pursuant to the authority herein given are hereby ratified and confirmed. Jln ltl!p:rrof, FRONTIER INSURANCE COMPANY of Rock Hill, New York. has caused this Power of Attorney to be signed by its President and its Corporate seal to be affixed this 16th day of May , 19 94 State of New York County of Sullivan 16th ss.: May FRONTIER INSURANCE COMPANY BY WALTER A. RHULEN, President On this day of , 19 . before the subscriber, a Notary Public ot the State of New York in and for the County of Suliivan, duly commissioned and Qualified, came WALTER A. RHULEN of FRONTIER INSURANCE COMPANY to me personally known to be the individual and officer described herein. and who executed the preceding instrument, and acknowledged the execution of the same, and being by me duly sworn, deposed and said, that he is the officer of the Company aforesaid, and that the seal affixed to the preceding instrument is the Corporate Seai of the Company. and the Corporate Sea! and signature as an officer were duly affixed and subscribed to the said instrument by the authority and direction of the Corporation. and that the resolution of the Company, referred to in the preceding instrument. is now in force JJn U::tstinuntu_ll11:rn'Of,! have hereunto set my hand, and affixed my official seal at Rock Hill, New York, the day and year above written. CERTIFICA TION CHRISTINE L LANE Notary Public State of New York Sullivan County Clerk's No. 1996 Commission Expires May 2. 1996 I, JOSEPH P. LOUGH UN, Secretary of FRONTIER INSURANCE COMPANY of Rock Hill, New York, do hereby certify thatthe foregoing Resolution adopted by the Board of Directors of this Corporation and the Powers of Attorney issued pursuant thereto, are true and correct, and that both the Resolution and the Powers of Attorney are in full force and effect. JJn 3illlittt('S5 ! have hereunto set my hand and affixed the facsimile sea: of the corporation this 21st day of 19 March 96 iL_ H P. LOUGHLIN, Secretary ---PAGE BREAK--- POST INSURANCE SERVICES P.O. BOX 8447 4477 EMERALD ST. #A-200 BOISE, ID 83707 COMPANY A LETTER 03119/96 COMPANIES AFFORDING COVERAGE COLORADO CASUALTY INS. CO. lr-!SURED COMP×NY B LEIT!:R SAFECO INSURANCE COMPANY A B Northwest Technologies Inc 6724 Emerald Boise, ID 83704 COMPANY C LETTER COMPANY LETITR D COMPeNY E LETThR FIDELITY ENVIRONMENTAL THIS IS TO CERTIFY THAT THE POLICJES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE INDICATED, NOTIVITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. TYPE OF INSURANCE POLICY El